Fairfield Connecticut Construction Expert Witness Directory

Graham & Who May Trigger The Need To Protest

December 23, 2023 — Hugo Fraga - Ahlers Cressman & Sleight PLLC
On May 30, 2023, the Washington Court of Appeals, Division I, issued a decision that appears to expand a contractor’s obligation with respect to WSDOT notice and claim procedures. In Graham Contracting, Ltd. v. City of Federal Way, No. 83494-1-I, 2023 WL 3721171 (Wash. Ct. App. May 30, 2023) (Unpublished), the Court held that under the 2016 WSDOT Standard Specifications for Road, Bridge, and Municipal Construction (“Standard Specifications”), a Contractor must protest the actions of not only the “Engineer” but also the actions of any person or organization acting on behalf of the Owner. This case arises out of a public construction contract in which Graham Contracting Ltd (“Graham”) built a multi-million dollar roadway improvement for the City of Federal Way along a stretch of Pacific Highway. The appeal was from the trial court’s granting of the City’s motion for summary judgment to dismiss claims by Graham for extra time and money due to delays and impacts to Graham’s construction of the Project. Read the full story...
Reprinted courtesy of Hugo Fraga, Ahlers Cressman & Sleight PLLC
Mr. Fraga may be contacted at hugo.fraga@acslawyers.com

A Look at Trending Legislative Changes Impacting Workers' Comp

February 26, 2024 — Rosanna Shamash - Construction Executive
The tides are shifting in the construction industry when it comes to legal matters—and business owners could feel the brunt of it. Recent legislative changes in the state of New York could signal how workers’ compensation cases move forward across the country and impact business owners in the space. Arguably, New York has historically laid the groundwork for workers’ compensation law in numerous other states. Now, we’re seeing a clear shift in favor of workers with some of the recent legislative changes. Owners, operators and executives in the construction space have increasingly found themselves facing costly claims that in years prior carried a smaller dollar value and were largely viewed as inconsequential. So, what’s the best way for business owners in the construction industry to protect their businesses for the future? Start by gaining a basic understanding of changes in the legal landscape, by securing defense attorneys who know the construction space and by taking steps to protect your business before an incident happens. Reprinted courtesy of Rosanna Shamash, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

Quick Note: October 1, 2023 Changes to Florida’s Construction Statutes

November 13, 2023 — David Adelstein - Florida Construction Legal Updates
Effective October 1, 2023, there were changes to Florida’s statutory scheme dealing with construction projects. This includes Florida’s Lien Law. A copy of these changes can be found below which identify additions in blue and deletions with strikethroughs. No different than before, if you have questions or concerns as to your statutory rights on a construction project, do the prudent thing, consult a construction lawyer. A construction lawyer can help you understand changes to the applicable statutory scheme or how the statutory scheme pertains to your rights. This is important because you want to make sure you understand statutory changes that apply to your work and rights. A noteworthy change, bolded in blue below, is that there is now a basis to lien for a contractor performing construction management services “which include scheduling and coordinating construction and preconstruction phases for the construction project, or who provides program management services”:

Fla. Stat. s. 713.01 (8) “Contractor” means a person other than a materialman or laborer who enters into a contract with the owner of real property for improving it, or who takes over from a contractor as so defined the entire remaining work under such contract. The term “contractor” includes an architect, landscape architect, or engineer who improves real property pursuant to a design- build contract authorized by s. 489.103(16). The term also includes a licensed general contractor or building contractor, as those terms are defined in s. 489.105(3)(a) and (b), respectively, who provides construction management services, which include scheduling and coordinating preconstruction and construction phases for the construction project, or who provides program management services, which include schedule control, cost control, and coordinating the provision or procurement of planning, design, and construction for the construction project.

Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

No Coverage for Roof Collapse During Hurricane

January 29, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The Fifth Circuit affirmed the district court's determination that the insured's roof collapse was not covered. Exclusive Real Estate Inv., L.L.C. v. S.G.L. No. 1, Ltd., 2023 U.S. App. LEXIS 29368 (5th Cir. Nov. 3, 2023). A building owned by Exclusive Real Estate partially collapsed during a rain-storm. The insurer, SGL, inspected the roof and determined that there was no coverage. Exclusive sued SGL for breach of contract and bad faith. SGL moved for summary judgment, which was granted by the district court. Exclusive appealed. The poicy covered "direct physical loss to the property" caused by windstorms. Exclusions, however, precluded coverage for losses "caused by rain, snow, sleet, sand or dust unless the direct force of wind or hail damages the building causing an opening in a roof or wall and the rain, snow, sleet, sand or dust enters through this opening." Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

The Word “Estimate” in a Contract Matters as to a Completion Date

February 12, 2024 — David Adelstein - Florida Construction Legal Updates
Language in a contract matters. The word “estimates” or “estimated” matters particularly when it comes to a date certain such as a substantial completion or completion date. Remember this. Here is an example. In Parque Towers Developers, LLC v. Pilac Management, Ltd., 49 Fla.L.Weekly D190a (Fla. 3d DCA 2024), a trial court held that the developer did not complete the construction of five condominium units by the date in the purchase agreements. The developer appealed because “[t]he agreements contain no date certain for the completion of the units, but rather include a clause that ‘Seller estimates it will substantially complete construction of the Unit, in the manner specified in this Agreement, by December 31, 2017, subject to extensions resulting from ‘Force Majeure (the ‘Outside Date’).’” Parque Towers, supra. Another provision in the purchase agreements stated, “[w]henver this Agreement requires Seller to complete or substantially complete any item of construction, that item will be understood to be complete or substantially complete when so completed or substantially completed in Seller’s opinion. Id. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Aarow Equipment v. Travelers- An Update

January 16, 2024 — Christopher G. Hill - Construction Law Musings
Previously here at Musings, I discussed the application of pay if paid clauses and the Miller Act. The case that prompted the discussion was the Aarow Equipment & Services, Inc. v. Travelers Casualty and Surety Co. case in which the Eastern District of Virginia Federal Court determined that a “pay if paid” clause coupled with a proper termination could defeat a Miller Act bond claim. However, as I found out a couple of weeks ago at the VSB’s Construction Law and Public Contracts section meeting, the 4th Circuit Court of Appeals reversed and remanded this case in an unpublished opinion (Aarow Equipment & Services, Inc. v. Travelers Casualty and Surety Co.) In it’s opinion, the 4th Circuit looked at some of the more “interesting” aspects of this case. One of these circumstances was that Syska (the general contractor) directed Aarow to construct sedimentary ponds and other water management measures around the project (the “pond work”), which both agreed was outside of the scope of the work defined in their subcontract. Syska asked that the government agree to a modification of the prime contract and asked Aarow to wait to submit its invoice for the pond work until after the government issued a modification to the prime contract and Syska issued a change order to the subcontract. Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

DOI Aims to Modernize its “Inefficient and Inflexible” Type A Natural Resource Damages Assessment Regulations

March 25, 2024 — Amanda G. Halter, Jillian Marullo & Ashleigh Myers - Gravel2Gavel Construction & Real Estate Law Blog
The U.S. Department of the Interior (DOI) published a proposed rule aimed at modernizing and streamlining the “Type A” Natural Resource Damage Assessment (NRDA) regulations under the Comprehensive Environmental Response, Compensation, and Liability Act (CERCLA) and the Clean Water Act (CWA). (The comment deadline was later extended.) The revisions, first previewed in a January 2023 Advanced Notice of Proposed Rulemaking (ANPR), are intended to fulfill “the original statutory purpose of providing a streamlined and simplified assessment process” with the overarching goal of facilitating settlements and expediting restoration efforts following injury resulting from pollution in a broader range of cases. The NRDA regulations provide two paths to assessing natural resource damages (NRD): (1) the more complex, site-specific Type B procedures for detailed NRDAs and (2) what is intended to be the standard, simplified Type A assessment procedures requiring minimal field observation. Particularly, the Type A process is reserved for two specific aquatic environments (coastal and marine areas or Great Lakes environments) when a relatively minor release of a single hazardous substance occurs, resulting in a smaller scale and scope of natural resource injury, and the rebuttal presumption for the Type A procedure is limited to damages of $100,000 or less under the current version of the rule. Reprinted courtesy of Amanda G. Halter, Pillsbury, Jillian Marullo, Pillsbury and Ashleigh Myers, Pillsbury Ms. Halter may be contacted at amanda.halter@pillsburylaw.com Ms. Marullo may be contacted at jillian.marullo@pillsburylaw.com Ms. Myers may be contacted at ashleigh.myers@pillsburylaw.com Read the full story...

9th Circuit Plumbs Through the Federal and State False Claims Acts

January 16, 2024 — Garret Murai - California Construction Law Blog
You may have heard of the False Claims Act and know that it penalizes companies and individuals in contract with the government who present false claims. The federal False Claims Act was signed into law by President Abraham Lincoln in 1863 to penalize profiteers during the Civil War who were selling the Union Army moth eaten blankets, boxes of sawdust instead of guns, and sometimes re-selling the Army calvary horses several times over. Since then, many states, including California, as well as municipalities, have enacted their own false claim statutes. As currently written, the federal False Claims Act provides for statutory penalties against any person who:

“[K]nowingly presents, or causes to be presented, a false or fraudulent claim for payment or approval”;
“[K]nowingly makes, uses or causes to be made or used, a false record or statement material to a false or fraudulent claim”;
“[H]as possession, custody, or control of property or money used, or to be used, by the Government an knowingly delivers, or causes to be delivered, less than all of that money or property”;

Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

FAIRFIELD CONNECTICUT CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES