FAIRFIELD CONNECTICUT CONSTRUCTION EXPERT WITNESS
DIRECTORY AND CAPABILITIES

Graham & Who May Trigger The Need To Protest

December 23, 2023 — Hugo Fraga - Ahlers Cressman & Sleight PLLC
On May 30, 2023, the Washington Court of Appeals, Division I, issued a decision that appears to expand a contractor’s obligation with respect to WSDOT notice and claim procedures. In Graham Contracting, Ltd. v. City of Federal Way, No. 83494-1-I, 2023 WL 3721171 (Wash. Ct. App. May 30, 2023) (Unpublished), the Court held that under the 2016 WSDOT Standard Specifications for Road, Bridge, and Municipal Construction (“Standard Specifications”), a Contractor must protest the actions of not only the “Engineer” but also the actions of any person or organization acting on behalf of the Owner. This case arises out of a public construction contract in which Graham Contracting Ltd (“Graham”) built a multi-million dollar roadway improvement for the City of Federal Way along a stretch of Pacific Highway. The appeal was from the trial court’s granting of the City’s motion for summary judgment to dismiss claims by Graham for extra time and money due to delays and impacts to Graham’s construction of the Project. Read the full story...
Reprinted courtesy of Hugo Fraga, Ahlers Cressman & Sleight PLLC
Mr. Fraga may be contacted at hugo.fraga@acslawyers.com

---

Corporate Transparency Act’s Impact on Real Estate: Reporting Companies, Exemptions and Beneficial Ownership Reporting (webinar)

December 04, 2023 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
On October 23, 2023, colleague Andrew Weiner and Kevin Gaunt, counsel at Hunton Andrews Kurth, examined the Corporate Transparency Act (CTA), effective Jan. 1, 2024, and its impact on real estate entities and transactions, including who is considered a reporting company subject to new beneficial ownership information (BOI) reporting requirements and whether an exemption applies. The panel also discussed certain state laws that impose similar reporting requirements as the CTA and described best practices for real estate counsel to assist their clients with preparing for the CTA’s implementation and ongoing compliance. The panel also reviewed other important considerations, including:

1. Which real estate entities will likely be most affected by the CTA’s implementation and why?
2. What exemptions may apply?
3. How will the CTA’s reporting requirements affect real estate transactions for lenders and investors/buyers?
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team


---

Calling Hurricanes a Category 6 Risks Creating Deadly Confusion

March 25, 2024 — Brian K Sullivan - Bloomberg
Category 5 has become part of the world’s lexicon to describe a disaster of monumental proportion. Now, thanks to climate change, a pair of scientists don’t think that is a dire enough level to describe hurricanes. They raise the possibility, on a “hypothetical” basis, for a Category 6. Global warming has increased the energy available for storms to grow stronger, according to a paper by Michael Wehner, senior scientist at the Lawrence Berkeley National Lab, and James Kossin, climate and atmospheric professor at the University of Wisconsin. Their work was published in Proceedings of the National Academy of Sciences of the US. The scientists make a case for adjusting the five-step, Saffir-Simpson Hurricane Wind Scale, which is used to describe hurricane power. A Category 5 is assigned when storm winds reach 157 miles per hour, and today that goes up to the limit of physics. Wehner and Kossin suggest considering anything over 192 mph a Category 6. Read the full story...
Reprinted courtesy of Brian K Sullivan, Bloomberg


---

White and Williams Selected in the 2024 Best Law Firms ranked by Best Lawyers®

December 04, 2023 — White and Williams LLP
White and Williams LLP is proud to be selected in the 2024 Best Law Firms ranked by Best Lawyers®. The firm was recognized in the National Rankings in four practice areas including both Bankruptcy and Creditor Debtor Rights/Insolvency and Reorganization Law and Insurance Law (Tier 1). In addition, the firm’s office locations in Philadelphia, New York City, Boston, Baltimore, Delaware and New Jersey were recognized for 30 practice areas in the Metropolitan rankings. Achieving a tiered ranking in Best Law Firms signals a unique combination of quality law practice and breadth of legal expertise. The Best Law Firms research methodology includes the collection of client and lawyer evaluations, peer review from leading attorneys in their field and review of additional information provided by law firms as part of the formal submission process. The 2024 Best Law Firms rankings can be accessed at www.bestlawfirms.com. 2024 Best Law Firms
National Tier 1
• Bankruptcy and Creditor Debtor Rights / Insolvency and Reorganization Law
• Insurance Law
National Tier 3
• Construction Law
• Litigation – Construction
Read the full story...
Reprinted courtesy of White and Williams LLP


---

Clean Energy and Conservation Collide in California Coastal Waters

March 19, 2024 — Nadia Lopez & Josh Saul - Bloomberg
Two of President Joe Biden’s biggest priorities — conservation and the switch to clean energy — are colliding in the ocean off California’s quiet Central Coast. Located halfway between San Francisco and Los Angeles, Morro Bay boasts a rich ecosystem of fish, otters and migrating whales that the Indigenous Chumash people want to protect with a new marine sanctuary. But 20 miles (32 kilometers) out, developers plan some of the West Coast’s first offshore wind farms, where 1,100-foot-tall turbines (335 meters) tethered to the seabed will help California cut its carbon emissions. One US government agency appears poised to approve the sanctuary. Another already leased 376 square miles of ocean for wind development, just outside the sanctuary’s boundaries. Now, a fight is brewing over whether the scenic bay itself should be left out of the sanctuary, to give undersea power cables from the wind farms a place to come onshore. Reprinted courtesy of Nadia Lopez, Bloomberg and Josh Saul, Bloomberg Read the full story...


---

Ruling Dealing with Constructive Changes, Constructive Suspension, and the Implied Covenant of Good Faith and Fair Dealing

January 22, 2024 — David Adelstein - Florida Construction Legal Updates
A dispute pending in the Armed Services Board of Contract Appeals (ASBCA) dealt with interesting legal issues on a motion to dismiss. See Appeals of McCarthy Hitt-Next NGA West JV, ASBCA No. 63571, 2023 WL 9179193 (ASBCA 2023). The dispute involves a contractor passing through subcontractor claims due to impacts caused by the COVID-19 pandemic and the government’s response to the pandemic. More particularly, the claim centers on the premise that the government “failed to work with [the contractor] in good faith to develop a collaborative and cooperative approach to manage and mitigate the impacts and delays arising from the COVID-19 pandemic.” See Appeals of McCarthy Hitt. The contractor (again, submitting pass through claims from subcontractors) claimed: (a) constructive changes to the contract entitling it to an equitable adjustment under the Changes clause of Federal Acquisition Regulation (F.A.R.) 52.243-4; (b) construction suspensions of the contractor’s work entitling it to an equitable adjustment under the Suspensions of Work clause of F.A.R. 52-242-14; and (c) the government breached the implied covenant of good faith and fair dealing. Each of these legal issues and theories will be discussed below because they are need-to-know legal issues. Keep these legal issues in mind, and the ASBCA’s ruling on the motion to dismiss as its analysis may demonstrate fruitful in other applications. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

The Top 3 Trends That Will Impact the Construction Industry in 2024

December 04, 2023 — The Hartford Staff - The Hartford Insights
As more than 40% of the current U.S. construction workforce will retire in the next decade, industry leaders need to equip themselves with the necessary resources to combat the shifting work environment.1 “Trends in the construction industry will fluctuate in the coming years, which can lead to additional risks for industry leaders. It will be important to think about how they can address any potential risk factors. A lot of leaders have been increasing their planning efforts and looking into technology solutions to combat the ongoing labor shortage,” said David DeSilva, head of construction at The Hartford. Here, he outlines the top three top trends for business leaders to watch in 2024. 1. Ongoing Labor Shortages Construction is an industry that traditionally has a high labor turnover rate, which means companies needs to hire more frequently. This only increases during labor shortages. The construction workforce is up against several factors, including an aging workforce and recruitment struggles. Read the full story...
Reprinted courtesy of The Hartford Staff, The Hartford Insights


---

Appraisal Goes Forward Even Though Insurer Has Yet to Determine Coverage on Additional Claims

December 11, 2023 — Tred R. Eyerly - Insurance Law Hawaii
The trial court's order granting the insured's motion to stay litigation and compel an appraisal was affirmed even though the insurer had not determined coverage on the insured's additional claims.Heritage Prop. & Cas. Ins. Co. v. Wellington Place HOA, 2023 Fla. App. LEXIS 6405 (Fla. Ct. App. Sept. 13, 2023). The insured homeowner's association reported roof damage to its insurer, Heritage, after Hurrican Irma struck. Heritage agreed the damage was covered, but issued no payment because the amount of loss was less than the deductible. The insured hired its own adjuster. The insured requested an extension of the policy's two year time limit to complete repairs because the claim was still in dispute and the insurer had not yet paid sufficient funds to allow necessary repairs. Heritage sent a revised estimate and asked the insured to send its adjuster's estimate in order to address any disputes. The insured submitted its adjuster's estimate of more than $6 million, including, for the first time, the cost to replace all the windows and sliding glass doors. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---