Inaccurate Representations Can Lead to Differing Site Conditions Claim
May 26, 2026 —
David Adelstein - Florida Construction Legal UpdatesIn the
prior posting, I discussed a case dealing with a differing site condition. In that case, the owner did not have an affirmative duty to make a representation and there was no inaccurate representation made by the owner that misled the contractor.
Well, what about when there is an inaccurate misrepresentation regarding the site? This was the circumstance in an older Florida case where a dredging contractor had a successful differing site conditions claim. See Jacksonville Port Authority v. Parkhill-Goodloe, Co., Inc., 362 So.2d 1009 (Fla. 1st DCA 1978).
The government provided inaccurate information as to the lack of rock that would be encountered during the dredging that was relied on by the dredging contractor. But the government had “
superior knowledge” that there was rock in an adjacent location based on a prior claim from a contractor, yet the government did not disclose the possibility that rock could be encountered.
Read the full story...Reprinted courtesy of
David Adelstein, Kirwin NorrisMr. Adelstein may be contacted at
dma@kirwinnorris.com
Managing Rising Costs and Shifting Legal Risk for Florida High-Rise and Condominium Projects
May 05, 2026 —
Stephen Hauptman - Ball Janik LLPFlorida's construction defect landscape is experiencing a major shift. The convergence of material and labor cost volatility, regulatory tightening, and increasingly complex litigation strategies is forcing associations, developers, and their counsel to rethink how they approach risk management and dispute resolution. For those managing large-scale condo and high-rise projects, the stakes have never been higher.
The Cost Volatility Trap
Construction material prices rose at a "staggering" 12.6% annualized rate during the first two months of 2026, according to
recent industry analysis. Tariff impacts are projected to lead to more increases of 5.4% to 6.8%, depending on property type. For associations facing construction defect claims, this volatility creates a cascading problem: repair scopes defined two years ago are now dramatically underpriced, and damage calculations that appeared reasonable at discovery are obsolete by the time of settlement.
Courts and mediators are increasingly scrutinizing how cost estimates were developed and whether they account for existing market circumstances. Associations must now commission updated repair assessments more frequently, a practice that increases investigation costs but strengthens the credibility of damage claims. Conversely, defendants are weaponizing cost inflation as a defense, arguing that claimed damages are speculative or inflated. The practical result: repair sequencing and phasing strategies have become critical litigation tools. Associations that can demonstrate a rational, cost-effective repair plan tied to current market data are more favorably placed in settlement negotiations.
Regulatory Pressure and Deliberate Timing
Florida's 2026 condo compliance regime has significantly changed the defect claims landscape. Elevated transparency requirements, stricter reserve funding mandates, and tightened building safety inspection protocols mean that associations now face dual pressures: Comply with new regulations while simultaneously handling construction defect exposure.
This regulatory environment is changing investigation and documentation strategy. Associations that delay defect investigation to avoid triggering reserve funding obligations or disclosure requirements are taking on considerable legal risk. Recent case law such as the Third District Court of Appeal's reaffirmation of Chapter 558's pre-suit mediation requirements, underscores Florida's intent to resolve disputes early. Associations that move deliberately and record carefully during the pre-suit phase gain leverage in mediation and reduce the risk of expensive litigation.
Timing also intersects with repair sequencing. Associations must now balance the urgency of compliance inspections against the strategic advantage of phased repairs. Some associations are using compliance deadlines as a forcing mechanism to accelerate settlement discussions, while others are sequencing repairs to demonstrate good-faith remediation efforts before litigation commences.
The Emerging Risk Transfer Challenge
As construction defect claims grow more complex and costly, the traditional risk transfer systems, such as design-build warranties, contractor bonds, and insurance, are proving inadequate. Developers and general contractors are increasingly shifting risk to subcontractors and material suppliers, fragmenting liability and complicating recovery efforts for associations. Permitting and approval friction is also creating new litigation pressure points. Delays in municipal approvals, changes to building code interpretations, and disputes over remedial work compliance continue to spawn collateral claims that go beyond the original defect. Associations must now anticipate not only defect liability but also regulatory compliance disputes with municipalities, creating a dual-front legal challenge.
For large communities, this means reconsidering the entire risk architecture. Insurance carriers are tightening coverage, and traditional indemnification chains are breaking down. Forward-thinking associations are engaging counsel earlier in the development process to negotiate clearer risk allocation provisions and more robust insurance requirements.
Taking a Data-Driven Approach
Managing rising costs and shifting legal risk in Florida's high-rise and condo market requires a more sophisticated, data-driven approach. Associations must commission frequent cost updates, move deliberately through pre-suit investigation and mediation, and challenge traditional assumptions about risk transfer. Developers and their counsel should view regulatory compliance not as a burden but as an opportunity to demonstrate good-faith risk management and strengthen settlement positioning.
The firms and associations that succeed in 2026 will be those that treat cost volatility, regulatory change, and litigation strategy not as separate challenges but as linked elements of a coherent risk management framework.
Stephen Hauptman is special counsel in Ball Janik LLP’s Fort Lauderdale office. He may be reached at shauptman@balljanik.com.
Segal McCambridge Shareholders and Associates Recognized in 2027 Best Lawyers in America®
September 01, 2026 —
Segal McCambridgeSegal McCambridge is pleased to announce that 24 firm shareholders and associates have been recognized in the 2027 editions of the Best Lawyers in America® and Best Lawyers: Ones to Watch® in America. Best Lawyers® is an elite global network of legal professionals recognized through a trusted, peer-reviewed distinction. For more than four decades, its Purely Peer Review® methodology has upheld the principle that recognition should be earned through the opinions of fellow attorneys, not marketing influence or paid listings. No fees are accepted for consideration or inclusion.
"This Best Lawyers recognition is especially meaningful because it reflects the caliber of advocacy our attorneys bring to clients every day, across a wide range of practice areas," said Jason P. Eckerly, Segal McCambridge Managing Shareholder. "We are proud to see so many of our colleagues honored for their legal skills, dedication, and professionalism. This continued recognition underscores the strength of our national platform and the depth of talent across our firm."
Segal McCambridge's attorneys named in Best Lawyers in America® include:
Jason P. Eckerly; Chicago, IL; Product Liability Litigation - Defendants
Scott R. Emery; New York, NY; Mass Tort Litigation / Class Actions - Defendants
Jay Evans; Pittsburgh, PA; Mass Tort Litigation / Class Actions - Defendants; Product Liability Litigation - Defendants
Richard H. Glucksman; Los Angeles, CA; Construction Law
Nathan R. Horne; Austin, TX; Construction Law; Litigation - Construction
Alice Sacks Johnston; Pittsburgh, PA; Commercial Litigation; Mass Tort Litigation / Class Actions - Defendants; Product Liability Litigation - Defendants
Patrick M. Kemp; Austin, TX; Litigation - Insurance
Mitchell P. Morinec; Chicago, IL; Commercial Litigation
Anthony J. Sbarra, Jr.; Milton, MA; Mass Tort Litigation / Class Actions - Defendants; Personal Injury Litigation - Defendants; Product Liability Litigation - Defendants
Alan J. Taylor; Southfield, MI; Litigation - Construction; Real Estate Law
Kenneth P. Williams; Southfield, MI; Insurance Law; Litigation - Insurance; Personal Injury Litigation - Defendants
David J. Yates; Southfield, MI; Personal Injury Litigation - Defendants
Segal McCambridge's attorneys named in Best Lawyers: Ones to Watch in America® include:
Masood Syed Ali; Chicago, IL; Labor and Employment Law - Management
Mari Bryn Dowdy; Austin, TX; Product Liability Litigation - Defendants
Chaniece M. Hill; Chicago, IL; Medical Malpractice Law - Defendants
Mandy Kolodkin; Indianapolis, IN; Personal Injury Litigation - Defendants
Jeffrey M. Marchese; New York, NY; Litigation - Construction
Courtney C. McLaren; Memphis, TN; Personal Injury Litigation - Defendants
Benjamin J. Nellans; Chicago, IL; Commercial Litigation
Christopher P. Norton; Los Angeles, CA; Commercial Litigation
Nelson T. Rainey; Memphis, TN; Family Law; Health Care Law; Personal Injury Litigation - Defendants
Nicholas E. Richardson; Tampa, FL; Insurance Law
Jordan B. Rosenberg; Philadelphia, PA; Personal Injury Litigation - Defendants
Ian M. Sadler; Austin, TX; Commercial Litigation; Insurance Law
About Best Lawyers®
Best Lawyers® is an elite global network of legal professionals recognized through trusted, peer-reviewed distinction. For over four decades, its Purely Peer Review® methodology has upheld the principle that recognition should be earned through the opinions of fellow attorneys, not marketing influence or paid listings. Each year, millions of confidential evaluations are collected worldwide, contributing to one of the legal industry's most rigorous and trusted vetting processes. Only about 5% of lawyers in the United States and 3% globally are recognized, reflecting the selectivity and credibility of the results. No fees are accepted for consideration or inclusion, maintaining the integrity and independence of all recognitions. For more information, visit: www.bestlawyers.com.
About Segal McCambridge
Segal McCambridge has built a reputation as a national law firm of accomplished trial attorneys for almost four decades. Founded in 1986, the firm has grown from a four-lawyer shop in Chicago to a firm with more than 20 offices nationwide. The firm routinely counsels and defends clients, including Fortune 500 companies, corporations, and individuals, across the United States in complex litigation matters including, but not limited to: asbestos, class action, construction, employment, environmental, food and beverage, insurance coverage and bad faith, life sciences, product liability, professional liability, technology and cyber risk, transportation, and warranty. For more information, visit: www.segalmccambridge.com.
Emerging Issues in Construction CGL Insurance Part 2: The Separation of Insureds and Additional Insured Interests
September 29, 2026 —
Eric M. Clarkson - SDV FenchurchMany coverage disputes hinge on first principles—the fundamentals of insurance —rather than the minutiae. Unfortunately, the basic anatomy of insurance policies can get lost sometimes when parties are laser-focused on a particular term or set of circumstances. This is true not just in disputes, but also when writing coverage. One of the fundamentals that is commonly misunderstood and overlooked—but which is absolutely critical to the intended operation of insurance coverage—is what is commonly known as the “separation of insureds.”
The “separation of insureds” is the concept that each “insured” under a policy are referred to and treated differently, and most of all that the distinctions matter. The concept is usually included as a condition in the policy. It embodies the requirement that the policy applies to each insured distinctly from how it applies to other insureds. The ISO Form CGL policies specifically state that they apply “[s]eparately to each insured against whom a claim is made or ‘suit’ is brought.” The separate and distinct treatment of insureds is more critical in construction operations than anywhere else. This distinction is essential to ensure coverage works as intended, especially when contracted operations are involved, because the policy must insure the subcontractor that purchased the policy, the general contractor who hired the subcontractor, and the owner that hired the general contractor. Even small modifications can easily frustrate the intent of the parties.
Read the full story...Reprinted courtesy of
Eric M. Clarkson, SDV FenchurchMr. Clarkson may be contacted at
eric.clarkson@sdvfenchurch.us
WSHB Managing Partner Chad Dunigan Named Finalist for Jerrold S. Oliver "Ollie" Award of Excellence
May 12, 2026 —
Wood Smith Henning BermanChad Dunigan, Managing Partner of Wood Smith Henning & Berman's Orlando, Florida, office, has been selected as one of just four finalists for the prestigious Jerrold S. Oliver Award of Excellence, affectionately known in the construction defect community as the "Ollie" Award. This distinguished honor recognizes individuals who have made exceptional contributions and demonstrated unwavering dedication to advancing the field of construction defect law.
Named in honor of the late Judge Jerrold S. Oliver, a revered founder of alternative dispute resolution in construction defect claims and litigation, the Ollie award symbolizes loyalty, commitment, and trust within the industry. Judge Oliver's legacy as a staunch believer in the resolution process continues to inspire professionals who strive for excellence in the construction defect community.
Read the full story...Reprinted courtesy of
Wood Smith Henning Berman
ACEC Supports BUILD America 250 Act as Important First Step on Surface Reauthorization
May 26, 2026 —
The American Council of Engineering CompaniesWASHINGTON -- The American Council of Engineering Companies (ACEC), the business voice of America’s engineering and design services industry released the following statement on the BUILD America 250 Act:
"Chairman Graves and Ranking Member Larsen have taken an important bipartisan step toward reauthorizing the federal surface transportation programs that are critical to economic growth in every state. The BUILD America 250 Act provides five years of stability in funding road and transit projects, raises new revenues to address the solvency of the Highway Trust Fund, and includes meaningful provisions to strengthen project delivery, advance digital infrastructure, and improve the contracting framework that engineering firms rely on every day. ACEC will continue to advocate for investment levels that keep pace with the country's growing infrastructure needs, and we urge the Committee to keep this process moving forward."
The American Council of Engineering Companies (ACEC) is the business association of America’s engineering industry, representing more than 5,500 independent engineering firms and more than 650,000 professionals throughout the United States engaged in the development of America’s transportation, water, and energy infrastructure, along with environmental, industrial, and other public and private facilities. Founded in 1906 and headquartered in Washington, D.C., ACEC is a national federation of 51 state and regional organizations.
The AI Knows Too Much: When Employees Feed Trade Secrets into Generative AI Tools
April 14, 2026 —
Kazim A. Naqvi & John V. Mysliwiec - SheppardEvery time an employee pastes proprietary source code, a customer list, or a confidential business strategy into
ChatGPT,
Claude, or
Google Gemini, they may be quietly dismantling the legal protections that make those secrets worth protecting. Courts and regulators are only beginning to grapple with this problem, and right now, the burden of preventing it falls squarely on employers.
The Legal Stakes
Under the federal
Defend Trade Secrets Act (“DTSA”) and the
Uniform Trade Secrets Act (“UTSA”) as adopted across most states, a trade secret plaintiff must show that the information at issue was subject to reasonable measures to maintain its secrecy. Courts have historically credited measures like confidentiality agreements, physical access controls, and employee training—but those safeguards were designed for a world of thumb drives and disgruntled employees. They were not built for a world where a well-meaning engineer can, in seconds, transmit an entire corpus of proprietary data to a third-party AI platform operating under terms of service that may permit the provider to use inputs for model training.
Reprinted courtesy of
Kazim A. Naqvi, Sheppard and
John V. Mysliwiec, Sheppard
Mr. Naqvi may be contacted at knaqvi@sheppard.com
Mr. Mysliwiec may be contacted at jmysliwiec@sheppard.com
Read the full story...
Kahana Feld Obtains Favorable Result in High-Exposure NY Premises Liability Case
June 15, 2026 —
Leigh Katz - Kahana FeldKahana Feld partner Leigh Katz obtained a significant victory in a recent matter involving a videotaped alleged trip and fall on the sidewalk in front of the client’s commercial residence. The plaintiff claimed he suffered a knee injury that necessitated surgery, along with other assorted injuries that prevented him from continuing high-level athletic activities. Leigh was able to demonstrate that the fall was staged and received a voluntary discontinuance with prejudice.
At mediation, Leigh emphasized that KF’s expert witness challenged the plaintiff’s claim that the fall was caused by a sidewalk height differential after reviewing the videotape footage and determining the plaintiff’s fall began before his feet made contact with the alleged defect. Based on this analysis, the expert concluded the reported height differential did not initiate the fall, which supported KF’s position that the incident depicted in the video was unrealistic and appeared staged.
Read the full story...Reprinted courtesy of
Leigh Katz, Kahana FeldMs. Katz may be contacted at
lkatz@kahanafeld.com
