Gouldbusk Texas Construction Expert Witness Directory

The Race to Reengineer Cybersecurity

October 06, 2026 — Emell D. Adolphus - Engineering News-Record
It took six days for Colonial Pipeline Co.'s 5,500-plus miles of connected refined petroleum supply infrastructure from Houston to New York City, to come back on line after a May 7, 2021 ransomware cyberattack forced the company to shut down operations and pay $4.4 million for restoration. Read the full story...
Reprinted courtesy of Emell D. Adolphus, Engineering News-Record
Mr. Adolphus may be contacted at adolphuse@enr.com

Project Labor Agreements: A New Bid Protest Forum Split

May 14, 2026 — Dirk D. Haire, David P.J. Timm and Michael J. Brewer - ConsensusDocs
Advertisements often include a disclaimer: “individual results may vary.” Similarly, lawyers are notorious for saying “it depends.” The mandatory Project Labor Agreement (“PLA”) regulations have recently placed into context this adage as it applies to federal contract bid protests, with very different results depending on which forum – the Court of Federal Claims (“COFC”) versus the Government Accountability Office (“GAO”) – different contractors have selected to bring PLA bid protests. Over the last two years, over 30 protesters have successfully achieved removal of mandatory PLAs from large-scale federal construction contracts based on two landmark bid protest decisions issued by the COFC. Similar challenges to PLAs at the GAO, however, have not been successful in removing PLAs, highlighting an emerging trend that the COFC is often a more effective relief forum than GAO for government construction contractors. Reprinted courtesy of Dirk D. Haire, Burr & Forman LLP, David P.J. Timm, Burr & Forman LLP and Michael J. Brewer, Burr & Forman LLP Mr. Haire may be contacted at dhaire@burr.com Mr. Timm may be contacted at dtimm@burr.com Mr. Brewer may be contacted at mbrewer@burr.com Read the full story...

From CERCLA to Drinking Water: D.C. Circuit’s PFAS Ruling Enters a Second Regulatory Fight

October 06, 2026 — Ashleigh K. Myers, Amanda G. Halter & Jillian Marullo - Gravel2Gavel Construction & Real Estate Law Blog
On August 18, 2026, a unanimous panel of the U.S. Court of Appeals for the D.C. Circuit upheld EPA’s designation of perfluorooctanoic acid (PFOA) and perfluorooctanesulfonic acid (PFOS) as hazardous substances under the Comprehensive Environmental Response, Compensation, and Liability Act (CERCLA or Superfund). In Chamber of Commerce of the United States v. EPA, the court rejected challenges to EPA’s interpretation of CERCLA Section 102(a), the adequacy of its notice and comment process, its analysis of costs and benefits, and its decision to proceed despite uncertainty about future response actions and costs. This decision is already being invoked in a separate D.C. Circuit challenge to EPA’s 2024 PFAS drinking water rule promulgated under the Safe Drinking Water Act (SDWA). Six days after the CERCLA decision, respondent intervenors cited it as supplemental authority in American Water Works Association v. EPA, No. 24-1188, ahead of oral argument scheduled for September 18, 2026. The Chamber of Commerce decision may assist the respondent intervenors on certain notice and comment and economic analysis arguments, but its significance should not be overstated. The principal challenges to the standards for the four PFAS subject to EPA’s Hazard Index-based maximum contaminant level (MCL) turn on requirements specific to the SDWA, and EPA itself now agrees that those provisions were promulgated through an unlawful process. Reprinted courtesy of Ashleigh K. Myers, Pillsbury, Amanda G. Halter, Pillsbury and Jillian Marullo, Pillsbury Ms. Myers may be contacted at ashleigh.myers@pillsburylaw.com Ms. Halter may be contacted at amanda.halter@pillsburylaw.com Ms. Marullo may be contacted at jillian.marullo@pillsburylaw.com Read the full story...

Credibility Matters…Even in Delay Claims

September 29, 2026 — David Adelstein - Florida Construction Legal Updates
Credibility matters. Here’s another example involving a delay claim on public private partnership delivery method. The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Endra Rethinks MEP Design with AI

July 06, 2026 — Aarni Heiskanen - AEC Business
Niklas Lindgren, co-founder and CEO of Endra, joins the AEC Business Podcast to discuss why his Stockholm-based startup is rebuilding MEP design from the ground up with AI. Endra recently raised $50 million in Series A funding and counts some of the world’s largest engineering consultancies as customers. Niklas explains why Revit’s underlying data model is too coarse to support deep automation, and why Endra built its own granular 3D data model instead of working as a plugin. He describes Endra’s “spatial AI” approach to routing conduit and ductwork without clashes, and how the platform models entire electrical systems, from receptacle to transformer, inside a single source of truth. Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Building More Than a Ramp: HHMR and the Home Builders Foundation

September 15, 2026 — Colorado Construction Litigation Blog
Last Friday, four members of the Higgins, Hopkins, McLain & Roswell team traded briefs, depositions, and construction litigation files for lumber, drills, and a day on a jobsite. HHMR attorneys Ricky Nolen, Amanda Tynan, Kyle Thompson, and Tanner Davis participated in the Home Builders Foundation’s 2026 Blitz Build, helping construct an accessibility ramp for Andrea, a Denver-area resident whose mobility challenges had made something most of us take for granted extraordinarily difficult: leaving her own home independently. The day after the build, the volunteers received an e-mail from HBF’s Terrina Reiber with an unusual request: set an alarm for 10:00 the next morning. At 10:00 on a Saturday, she explained, they might be running errands, meeting a friend, or simply deciding what to do with the day. When the alarm went off, she asked them to think about Andrea. Because Andrea could now make that same choice. Read the full story...
Reprinted courtesy of Higgins, Hopkins, McLain & Roswell

GRSM Secures Illinois Appellate Victory for Architectural Firm in Implied Warranty Dispute

May 14, 2026 — Gordon Rees Scully Mansukhani
Gordon Rees Scully Mansukhani Partner Jonathan Federman, Partner Thomas Cronin, and Senior Counsel Garrett Lee recently secured a victory in the Illinois Appellate Court, Fifth District, on behalf of the firm’s client, an architectural firm, in a liability dispute. The case arose following an entity’s purchase of a 111-unit building for use as an investment or rental property. The plaintiff made claims against the architect of the building, alleging that there were design defects that breached an implied warranty, as well as a negligence claim. GRSM argued that an architect could not be liable for implied warranties, particularly for an implied warranty which no Illinois court has ever recognized. GRSM further argued that Illinois law bars an architect from liability for negligence arising from a duty pursuant to contract under the economic loss doctrine. Read the full story...
Reprinted courtesy of Gordon Rees Scully Mansukhani

$27B Meta Data Center Pushes Louisiana Toward Massive Power Expansion

April 27, 2026 — Vince Kong - Engineering News-Record
Meta Platforms has reached an agreement with Entergy Louisiana to fund new energy infrastructure to support its planned $27-billion data center in Richland Parish, a project the company says could ultimately scale to 5 GW, becoming its largest facility to date. CEO Mark Zuckerberg has described the site as large enough to cover a significant portion of Manhattan. Read the full story...
Reprinted courtesy of Vince Kong, Engineering News-Record
Mr. Kong may be contacted at kongv@enr.com

GOULDBUSK TEXAS CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES