LAS VEGAS NEW MEXICO CONSTRUCTION EXPERT WITNESS
DIRECTORY AND CAPABILITIES

Settlement Agreements and Contracts Require a Meeting of the Minds

July 20, 2026 — David Adelstein - Florida Construction Legal Updates
A settlement agreement does not need to be executed for it to be enforceable as long as there was a MEETING OF THE MINDS. The same rings true for any contract regardless of whether the contract is signed – THERE NEEDS TO BE A MEETING OF THE MINDS. In a recent case dealing with the settlement agreement on a construction lien, the essential settlement terms (money and mutual release) were memorialized in an e-mail exchange between the parties (owner and subcontractor). The settlement required the owner to pay the principal amount plus some attorney’s fees and then a mutual general release would be prepared. In response to the confirmatory email, the owner sent a check, which the subcontractor deposited, but the owner refused to sign the release signed and sent by the subcontractor. The owner further claimed it doesn’t need to pay the attorney’s fees because the lien amount was paid in full. The subcontractor sued arguing the owner breached the terms of the settlement. The appellate court agreed. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Wilke Fleury Attorneys Recognized by 2026 Northern California Super Lawyers and Rising Stars!

July 20, 2026 — Wilke Fleury
Wilke Fleury is pleased to announce that 18 of the firm’s attorneys have been selected for inclusion on the 2026 Northern California Super Lawyers and Rising Stars lists. The annual Super Lawyers and Rising Stars selections recognize attorneys across a wide range of practice areas. This year’s honorees reflect the depth of Wilke Fleury’s litigation, business, healthcare, employment, bankruptcy, appellate, real estate, construction, and estate planning practices. Read the full story...
Reprinted courtesy of Wilke Fleury

---

Nicole Whyte is the Newly Elected Secretary of the Orange County Bar Association

September 28, 2026 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
“I am deeply honored to serve as Secretary of the Orange County Bar Association. To everyone who supported me, endorsed me, encouraged me, shared my message, and cast a ballot, thank you. I am profoundly grateful for your trust and confidence. Thank you from the bottom of my heart. I am ready to get to work.” – Nicole Whyte Read the full story...
Reprinted courtesy of Bremer Whyte Brown & O'Meara LLP

---

NJ Public Works Contractors Beware – Pay Special Attention When Submitting Your Public Works Contractor Registration

May 26, 2026 — Levi W. Barrett & Aaron C. Schlesinger - Peckar & Abramson, P.C.
While it is always important to be careful when making submissions to government agencies, recent activity by the New Jersey Department of Labor and Workforce Development (“NJDOL”) reveals considerably increased scrutiny in connection with contractors renewing their New Jersey Public Works Registration. Extra care when completing the registration renewal process is warranted, because the consequences of a misstep can be significant and disruptive. The New Jersey Public Works Contractor Registration Act requires all contractors bidding on or engaging in construction-related public works projects to register with the NJDOL. This registration, which must be resubmitted every 1-2 years, requires contractors to make a number of detailed disclosures relating to, among other things, the entity’s ownership structure, prior state and federal labor law violations, details regarding interests in other businesses, unlawful acts by owners/officers, and participation in apprenticeship programs. Reprinted courtesy of Levi W. Barrett, Peckar & Abramson, P.C. and Aaron C. Schlesinger, Peckar & Abramson, P.C. Mr. Barrett may be contacted at lbarrett@pecklaw.com Mr. Schlesinger may be contacted at aschlesinger@pecklaw.com Read the full story...

---

Bad Faith Claim Survives Summary Judgment

June 08, 2026 — Tred R. Eyerly - Insurance Law Hawaii
The court denied the insurer’s motion for partial summary judgment on the insured’s bad faith claim, but granted the motion on the insured’s claim for punitive damages. Serbian Orthodox Church v. Brotherhood Mut. Ins. Co., 2026 U.S. Dist. LEXIS 58234 (S.D. Cal. March 19, 2026). On February 1, 2023, the Church filed a claim for water damage with Brotherhood Mutual Insurance Company (BMIC). The claim was based on rain and wind that caused extensive water intrusion into the Sanctuary, damaging its plaster walls and ceilings and fresco paintings. The claim was assigned to Patrick Hurley. Hurley sent a letter discussing potential bars to coverage and requesting further information and documents from the Church. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Credibility Matters…Even in Delay Claims

September 29, 2026 — David Adelstein - Florida Construction Legal Updates
Credibility matters. Here’s another example involving a delay claim on public private partnership delivery method. The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Inaccurate Representations Can Lead to Differing Site Conditions Claim

May 26, 2026 — David Adelstein - Florida Construction Legal Updates
In the prior posting, I discussed a case dealing with a differing site condition. In that case, the owner did not have an affirmative duty to make a representation and there was no inaccurate representation made by the owner that misled the contractor. Well, what about when there is an inaccurate misrepresentation regarding the site? This was the circumstance in an older Florida case where a dredging contractor had a successful differing site conditions claim. See Jacksonville Port Authority v. Parkhill-Goodloe, Co., Inc., 362 So.2d 1009 (Fla. 1st DCA 1978). The government provided inaccurate information as to the lack of rock that would be encountered during the dredging that was relied on by the dredging contractor. But the government had “superior knowledge” that there was rock in an adjacent location based on a prior claim from a contractor, yet the government did not disclose the possibility that rock could be encountered. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Insureds’ Altering Dates for Hailstorm Damage Justifies Denial of Claim

June 02, 2026 — Tred R. Eyerly - Insurance Law Hawaii
The Firth Circuit affirmed the district court’s grant of summary judgment to the insurer due to the insureds’ failure to establish the date of loss after a hailstorm. Cutchall v. Chubb Lloyds Ins. Co. of Texas, 2026 WL 625633 (5th Cir. March 5, 2026). In September 2021, the Cutchalls made a claim on their policy for interior water damage due to a hailstorm that breached their roof. Chubb retained two engineers to inspect the home, but neither found evidence that a hailstorm caused the damage. Instead, the engineers concluded a variety of other causes, such as poor ventilation and as-built defects, caused the damage. Because Chubb concluded that some of these other causes were covered by the policy, it paid only for the covered portions. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---