HARVARD NEBRASKA CONSTRUCTION EXPERT WITNESS
DIRECTORY AND CAPABILITIES

Seventh Circuit, With an Assist From the Illinois Supreme Court, Finds That “Pollution Exclusion” Bars Coverage For Emissions Allowed Under Regulatory Permit

April 20, 2026 — Jason Taylor - Traub Lieberman Insurance Law Blog
In Griffith Foods Int’l Inc. v. National Union Fire Ins. Co. of Pittsburgh, PA, 24-1217 & 24-1223 (7th Cir. Mar. 13, 2026), the Seventh Circuit addressed the meaning and scope of a pollution exclusion in a standard-form commercial general liability insurance policy for underlying injuries caused by ethylene oxide (EtO) emissions. The insurance dispute arose out of underlying tort litigation involving bodily injury claims, including cancer, allegedly caused by emissions of ethylene oxide over a 35-year period from 1984 through 2019 by Griffith Foods International and later Sterigenics U.S. The pollution exclusion at issue generally barred coverage for “bodily injury” arising out of the discharge, dispersal, release or escape of smoke, vapors, soot, fumes, acids, alkalis, toxic chemicals, or other irritants, contaminants or pollutants. Interpreting similar exclusions, the Illinois Supreme Court has previously held that the standard CGL pollution exclusion bars coverage for bodily injuries caused by traditional environmental pollution (essentially industrial emissions of pollutants), but not by more commonplace emissions (such as carbon monoxide from a residential furnace or excess chlorine in a backyard swimming pool). See American States Insurance Co. v. Koloms, 177 Ill. 2d 473 (Ill. 1997). In Griffith Foods, the District Court initially concluded that the pollution exclusion did not apply because the companies emitted EtO pursuant to a permit issued by the IEPA. The District Court reached this latter conclusion by applying Erie Insurance Exchange v. Imperial Marble Corp., 957 N.E.2d 1214 (Ill. App. Ct. 2011), an Illinois intermediate appellate court decision finding it ambiguous whether a CGL policy’s pollution exclusion barred coverage for emissions authorized by regulatory permit. Read the full story...
Reprinted courtesy of Jason Taylor, Traub Lieberman
Mr. Taylor may be contacted at jtaylor@tlsslaw.com

---

Potential Gap in Workers Compensation Immunity Statutory Framework

June 02, 2026 — David Adelstein - Florida Construction Legal Updates
Workers compensation insurance is important. As an owner, you want to ensure the contractors you hire have workers compensation insurance. Assuming you hire a contractor that is statutorily exempt from workers compensation, you want to make sure, no exception, that any subcontractor that is hired has workers compensation insurance. (Regardless, you always want subcontractors to have workers compensation insurance.). In construction, the prime contractor serves as the “statutory employer” for purposes of workers compensation insurance. With workers compensation comes workers compensation immunity. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Credibility Matters…Even in Delay Claims

September 29, 2026 — David Adelstein - Florida Construction Legal Updates
Credibility matters. Here’s another example involving a delay claim on public private partnership delivery method. The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

What Massachusetts Contractors and Developers Can Learn from Cannistraro v. Columbia Construction

July 13, 2026 — Anthony LaPlaca & Luke Marston - The Construction Seyt
Introduction On June 26, 2026 the Massachusetts Supreme Judicial Court issued its decision in J.C. Cannistraro, LLC v. Columbia Construction Co.—a holding that sits at the intersection of Prompt Pay Act compliance and the Massachusetts Arbitration Act.[1] Most already know that the Massachusetts Prompt Pay Act (PPA) imposes strict timing and certification requirements for rejecting payment applications and proposed change orders on projects valued at $3 million or more. Most notably, the PPA requires the paying party to give the payee written notice of its approval or rejection of progress applications and proposed changes within 15 days of receipt, which notice must include a “factual and contractual basis for the rejection” and must be “certified as made in good faith.”[2] In the absence of a timely certified notice, payment is “deemed to be approved” unless the payor properly rejects payment before it comes due.[3] Reprinted courtesy of Anthony LaPlaca, Seyfarth Shaw LLP and Luke Marston, Seyfarth Shaw LLP Mr. LaPlaca may be contacted at alaplaca@seyfarth.com Mr. Marston may be contacted at lmarston@seyfarth.com Read the full story...

---

Construction Liens and the “Substantial Performance” Doctrine

April 08, 2026 — David Adelstein - Florida Construction Legal Updates
In a recent case dealing with a construction lien, the driving issue was whether the air conditioning contractor “substantially performed” before recording its construction lien against residential property. The importance here pertains to the substantial performance doctrine with respect to construction liens. The Third District Court of Appeal explained, with relevant citations, this doctrine as follows: Under Florida law, a contractor is entitled to a mechanic’s lien if he complies with all provisions of Chapter 713, governing construction liens, and “has substantially performed the contract.” Grant v. Wester, 679 So. 2d 1301, 1307 (Fla. 1st DCA 1996) (quotation omitted); Langley v. Knowles, 958 So. 2d 1149, 1151 (Fla. 5th DCA 2007) (“The substantial performance doctrine recognizes that a contactor who complies with all of the provisions of the contactor’s lien statute is entitled to enforce a lien if he has substantially, but not completely, performed his contractual obligations.”). Substantial performance is performance “so nearly equivalent to what was bargained for that it would be unreasonable to deny the promisee the full contract price subject to the promisor’s right to recover whatever damages may have been occasioned him by the promisee’s failure to render full performance.” Ocean Ridge Dev. Corp. v. Quality Plastering, Inc., 247 So. 2d 72, 75 (Fla. 4th DCA 1971). Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Wadsworth v. Regional Rail Partners — Verified Statements of Claim Under the Colorado Public Works Act

August 25, 2026 — Olivia Barden - Colorado Construction Litigation Blog
Editor’s Note: Wadsworth Revisited In August 2024, following the Colorado Court of Appeals’ decision in Ralph L. Wadsworth Construction Company, LLC v. Regional Rail Partners, we published Colorado Court of Appeals’ Ruling Highlights Dangers of Excessive Public Works Claims. At the time, the decision warranted a significant warning to contractors and subcontractors performing public work in Colorado. The Court of Appeals concluded that Wadsworth’s verified statement of claim improperly included unliquidated delay damages and that, because the claim was excessive, Wadsworth forfeited its right to recover the amounts included in the claim. We cautioned contractors to carefully scrutinize verified statements of claim and to avoid including unliquidated damages or amounts that were not yet due and payable. The Colorado Supreme Court has now reversed that decision. Read the full story...
Reprinted courtesy of Olivia Barden, Higgins, Hopkins, McLain & Roswell, LLC

---

4th Department Narrowly Interprets Professional Services

August 11, 2026 — Craig Rokuson - Traub Lieberman
In the recent case of Cty. of Erie v. Selective Ins. Co. of Am., 2026 NY Slip Op 04092 (App. Div. 4th Dept.), New York’s Appellate Division, Fourth Department held that a general liability carrier for a construction manager owed additional insured coverage to the County of Erie, notwithstanding an exclusion in the construction manager’s policy for injuries arising out of professional services. The underlying case involved injuries sustained when the underlying plaintiff fell off of her bicycle at a park owned by the County when she transitioned from the pavement edge to grass. Read the full story...
Reprinted courtesy of Craig Rokuson, Traub Lieberman
Mr. Rokuson may be contacted at crokuson@tlsslaw.com

---

Self-Healing Infrastructure Could Pave the Road to the Future

May 05, 2026 — Allan C. Van Vliet - Gravel2Gavel Construction & Real Estate Law Blog
A single hairline crack in a bridge deck can seem insignificant. But left undetected, minor cracks and fissures expand, water seeps in, steel corrodes and repair costs start to increase. This risk multiplies across thousands of miles of aging highways and bridges nationwide. As infrastructure endures increasing strain from heavier traffic, extreme weather and deferred maintenance, engineers are exploring “self-healing” systems, where streets and bridges are built with materials that can repair themselves. Concrete, asphalt and composites capable of detecting and mending microcracks autonomously are moving from laboratory research to pilot projects. But while emerging technology promises longer-lasting infrastructure, it also raises questions about long-term maintenance, performance guarantees, procurement frameworks and risk allocation. Read the full story...
Reprinted courtesy of Allan C. Van Vliet, Pillsbury
Mr. Van Vliet may be contacted at allan.vanvliet@pillsburylaw.com

---