Wilton Minnesota Construction Expert Witness Directory

We Won’t Permit That Excuse!

June 23, 2026 — Curt Martin & Richard Eiszner - ConsensusDocs
A Texas appellate court recently ruled that a building permit wasn’t a condition precedent for a construction project. That caught our attention. Can you build a commercial project without a permit? But as we read the case, we see the court’s reasoning. And it reminds us of an important legal principle that should inform our contract drafting and negotiation. The case was a civil suit brought by the project owner against its tenant improvement contractor for work on a medical spa. The owner claimed that the contractor didn’t perform the work properly and didn’t finish construction. The contractor argued that delays and problems were caused by the owner, alleging numerous failures, including the owner’s failure to secure a building permit. Reprinted courtesy of Curt Martin, Peckar & Abramson, P.C. and Richard Eiszner, Peckar & Abramson, P.C. Mr. Martin may be contacted at cmartin@pecklaw.com Mr. Eiszner may be contacted at reiszner@pecklaw.com Read the full story...

Federal Bid Protest Standard of Review and Disparate Treatment with Ratings

August 16, 2026 — David Adelstein - Florida Construction Legal Updates
A recent decision out of the Federal Claims Court explains the post-award bid protest standard of review. In Massman Construction Co. v. U.S., 2026 WL 1971985 (Fed.Cl. 2026), a protestor brought a post-award bid protest after the Army Corps of Engineers awarded the contract to another contractor. The protestor argued that the Army Corps (government) acted irrational in its evaluation through disparate treatment. The Court of Federal Claims agreed and remanded for the Army Corps to “either justify this disparity or explain why [awardee’s] lower-priced, but technically inferior proposal provides the best value to the government.” Massman Construction, supra at *1. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

IRMI Expert Commentary: NY Highest Court Confronts Downstream Risk Transfer for Subcontractor Bodily Injury Claims

March 17, 2026 — Gregory D. Podolak & Alexander G. Hopkins - Saxe Doernberger & Vita, P.C.
Originally published on IRMI.com, copyright 2026 International Risk Management Institute, Inc. Subcontractor employee bodily injury claims (so-called action over claims) are a staple of construction risk management in the Empire State—so much so that the phrase “labor law” instinctively invites a shudder among the most experienced general contractors. The savvy among them intensely monitor case law developments and the evolution of the insurance market to ensure a cutting-edge, meticulously developed downstream risk transfer plan. And when guidance arrives from an appellate-level court, it’s a moment to take note. This is one of those moments. In late 2025, New York’s highest court—the NY Court of Appeals—had the rare opportunity to examine an all-too-routine bodily injury fact pattern and took the opportunity to closely examine the scope of contractual indemnity and its interplay with additional insured coverage in Dibrino v. Rockefeller Center N., Inc., 2025 N.Y. Slip Op. 07077, 2025 WL 3670593 (Ct. App. Dec. 18, 2025). Reprinted courtesy of Gregory D. Podolak, Saxe Doernberger & Vita, P.C. and Alexander G. Hopkins, Saxe Doernberger & Vita, P.C. Mr. Podolak may be contacted at GPodolak@sdvlaw.com Mr. Hopkins may be contacted at AHopkins@sdvlaw.com Read the full story...

California Enacts Change Order Fair Payment Act

March 24, 2026 — Michael J. Baker - Snell & Wilmer
For private works construction contracts entered on or after January 1, 2026, recent legislation establishes a claims and dispute resolution process for change orders. The law is codified at Civil Code § 8850. A synopsis of the pertinent provisions includes the following:

Submitting a Claim. Contractors or subcontractors must submit a detailed, documented claim when requesting additional time or payment.
Owner’s Response Time. The owner must meet and confer within thirty (30) days after receiving the claim. Within ten (10) days of meeting, the owner must provide a written statement identifying which portions of the claim are undisputed and which are disputed. An owner’s failure to respond is treated as disputing the entire claim.

Read the full story...
Reprinted courtesy of Michael J. Baker, Snell & Wilmer
Mr. Baker may be contacted at mjbaker@swlaw.com

PJM’s Reliability Backstop Procurement Proposal—Fast-Track Capacity to Meet Rising Large-Load Demand

May 12, 2026 — Stephen J. Humes, Alicia M. McKnight, Jason Drogin Atwood & Andrew H. Jacobs - Gravel2Gavel
In January, we discussed the Statement of Principles jointly signed by the National Energy Dominance Council and governors across the mid-Atlantic region—framing accelerating demand (especially from large-scale data centers) as an emergency reliability issue for PJM Interconnection, L.L.C. (PJM), the nation’s largest power grid operator. That policy signal is now becoming a near-term, accelerated procurement and contracting exercise. On April 8, 2026, PJM notified stakeholders of a critical issue fast path reliability backstop procurement process. PJM subsequently released a request for information (RFI) with respect to a proposed Reliability Backstop Procurement (RBP)—a one-time mechanism intended to attract significant new capacity to address projected reliability shortfalls driven by large-load growth. RBP compresses what is often a multiyear market and regulatory conversation into a fast-moving set of commercial choices. Developers, large loads, utilities and capital providers should be preparing now for (i) an accelerated bilateral contracting window and (ii) a standardized PJM-led backstop procurement if bilateral deals do not clear enough capacity. Reprinted courtesy of Stephen J. Humes, Pillsbury, Alicia M. McKnight, Pillsbury, Jason Drogin Atwood, Pillsbury and Andrew H. Jacobs, Pillsbury Mr. Humes may be contacted at stephen.humes@pillsburylaw.com Ms. McKnight may be contacted at alicia.mcknight@pillsburylaw.com Mr. Atwood may be contacted at jason.atwood@pillsburylaw.com Mr. Jacobs may be contacted at andrew.jacobs@pillsburylaw.com Read the full story...

Insureds’ Altering Dates for Hailstorm Damage Justifies Denial of Claim

June 02, 2026 — Tred R. Eyerly - Insurance Law Hawaii
The Firth Circuit affirmed the district court’s grant of summary judgment to the insurer due to the insureds’ failure to establish the date of loss after a hailstorm. Cutchall v. Chubb Lloyds Ins. Co. of Texas, 2026 WL 625633 (5th Cir. March 5, 2026). In September 2021, the Cutchalls made a claim on their policy for interior water damage due to a hailstorm that breached their roof. Chubb retained two engineers to inspect the home, but neither found evidence that a hailstorm caused the damage. Instead, the engineers concluded a variety of other causes, such as poor ventilation and as-built defects, caused the damage. Because Chubb concluded that some of these other causes were covered by the policy, it paid only for the covered portions. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Endra Rethinks MEP Design with AI

July 06, 2026 — Aarni Heiskanen - AEC Business
Niklas Lindgren, co-founder and CEO of Endra, joins the AEC Business Podcast to discuss why his Stockholm-based startup is rebuilding MEP design from the ground up with AI. Endra recently raised $50 million in Series A funding and counts some of the world’s largest engineering consultancies as customers. Niklas explains why Revit’s underlying data model is too coarse to support deep automation, and why Endra built its own granular 3D data model instead of working as a plugin. He describes Endra’s “spatial AI” approach to routing conduit and ductwork without clashes, and how the platform models entire electrical systems, from receptacle to transformer, inside a single source of truth. Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Labor Shortages in Construction: Managing Legal and Operational Risks

April 14, 2026 — Meghan Douris - Construction Executive
Labor shortages in the construction industry have become more than a scheduling headache—they are a legal and financial risk multiplier. As contractors scramble to meet deadlines with limited manpower, shortcuts in compliance, safety and subcontractor oversight become more likely. These gaps can expose companies to regulatory penalties, contractual disputes and reputational damage. Understanding how workforce constraints intersect with labor laws and contractual obligations is critical to mitigating the risks and navigating these challenges without compromising compliance or project integrity. The construction industry has faced persistent workforce challenges for years, but recent trends have intensified the problem. Factors such as an aging workforce, reduced immigration and post-pandemic recovery pressures have left contractors struggling to find skilled labor. According to Associated Builders and Contractors, the construction workforce shortage surpassed half a million workers in 2024; in the same year, Associated General Contractors reported 88% of construction companies had difficulty finding qualified workers. Reprinted courtesy of Meghan Douris, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

WILTON MINNESOTA CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES