Varina Iowa Construction Expert Witness Directory

Can Anything Supersede Excel in AEC?

April 27, 2026 — Aarni Heiskanen - AEC Business
If there’s one piece of software that dominates the business world across industries, it’s Microsoft Excel. Can AI finally dethrone the mighty spreadsheet? Memorable Spreadsheet Moments Everyone has memorable spreadsheet moments. I have a few. For example, my then-architecture firm was involved in more than a dozen housing developments abroad. I developed an Excel workbook that took the required number of households as input and automatically generated a breakdown of buildings and their apartment types for AutoCAD. This was urban planning and architectural design done with a spreadsheet. I also developed business software using Excel for project portfolio management. The prototype was later scaled into a commercial SaaS that is now used globally. Another memorable moment was when a property owner told me their Excel file grew so large that it ran out of rows and columns. That must have been before 2007, when the maximum number of columns on a sheet was still just 256 and the maximum number of rows was 65,536. The current limits are 1,048,576 rows and 16,384 columns, which I hope no one will exceed. Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Shane Singh Named One of Los Angeles Business Journal's 'Top 100 Lawyers of Los Angeles' for 2026

April 27, 2026 — Lewis Brisbois
Sacramento Partner Shane Singh has been named one of the Los Angeles Business Journal's "Top 100 Lawyers of Los Angeles" for 2026. The LABJ’s annual list honors Los Angeles' top lawyers for their achievements within the city's business community. Read the full story...
Reprinted courtesy of Lewis Brisbois

Traub Lieberman Recognized in the 2026 Edition of Chambers USA

June 29, 2026 — Traub Lieberman
In the 2026 edition of Chambers USA, Traub Lieberman has been awarded rankings in the following categories: Illinois – Insurance: Dispute Resolution: Insurer In the Chambers research, clients noted: "The team are technically very strong, responsive, and on top of their cases." Florida – Insurance: Dispute Resolution: Insurer In the Chambers research, clients noted: "Traub Lieberman Straus & Shrewsberry distinguishes itself through a combination of deep subject-matter expertise, responsiveness, and practical risk-management orientation." Commenters went on to say: “The team has deep knowledge of Florida property insurance statutes, regulations and case law, enabling effective handling of disputes, appeals and third-party litigation." Read the full story...
Reprinted courtesy of Traub Lieberman

Credibility Matters…Even in Delay Claims

September 29, 2026 — David Adelstein - Florida Construction Legal Updates
Credibility matters. Here’s another example involving a delay claim on public private partnership delivery method. The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Amanda Mathieu Named to Massachusetts Lawyers Weekly 2026 “Top Women of Law” List

September 21, 2026 — Lewis Brisbois
Massachusetts Lawyers Weekly recently named Boston Deputy Managing Partner Amanda Mathieu to its 2026 “Top Women of Law” list, which honors leaders who have shown excellence, innovation, and meaningful contributions to the industry and their communities. According to the publication, “Top Women of Law honorees represent the very best of Massachusetts’ legal community—from accomplished advocates and firm leaders to pioneers, educators, trailblazers, and role models driving positive change throughout the profession. Their influence extends beyond the courtroom and boardroom, creating a lasting impact on their clients, colleagues, organizations, and communities.” “We are lucky to have Amanda as a leader in our Boston office, and a mentor to so many Lewis Brisbois Associates who are getting their careers started in the legal profession” said Managing Partner Ken Walton on this recognition. “This is a well-deserved honor for her, and I look forward to continuing to continuing to work with her as we deliver excellent results for our clients across the country." Read the full story...
Reprinted courtesy of Lewis Brisbois

Newmeyer Dillion Partner Jeff Masters Recognized by Chambers USA for Representation of Insurance Policyholders

June 08, 2026 — Newmeyer Dillion
NEWPORT BEACH, Calif. – June 4, 2026 – Newmeyer Dillion is proud to announce that litigation partner Jeffrey D. Masters has been ranked among a select group of California lawyers representing insurance policyholders in the 2026 edition of Chambers USA. This marks two consecutive years of recognition for Masters by this prestigious international attorney rating resource. "This recognition by Chambers and Partners is a testament to Jeff’s dedication to our clients," said Managing Partner, Paul Tetzloff. "We are thrilled to see his hard work acknowledged and the level of passion and care that he delivers to clients fully recognized." Read the full story...
Reprinted courtesy of Newmeyer Dillion

Turning Expert Services into Products

July 20, 2026 — Aarni Heiskanen - AEC Business
A Finnish engineering, architecture, and project consulting company, AINS Group, recently opened an online store to purchase fixed-price services. The store presents specialist work in a product-like format, with fixed service names, defined scopes, and visible prices, such as a building history report, a zoning plan cost analysis, and a technical preliminary survey for a property transaction. Is this productization a smart move or a sign that expert services are being commoditized? Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Navigating the New Frontier of Federal-State Energy Regulation: What Energy Companies Need to Know

June 08, 2026 — Ryan J. Regula - Snell & Wilmer
Introduction The jurisdictional boundary between the Federal Energy Regulatory Commission (FERC) and the states is being actively contested, from challenges to landmark transmission planning rules to disputes over emergency cost-allocation orders, in ways that carry significant legal, financial, and operational implications for energy companies. For utilities, independent power producers, and transmission developers, understanding these dynamics is now a strategic imperative. The Jurisdictional Divide: A Bright Line That Isn’t The Federal Power Act divides authority between FERC and the states: FERC exercises jurisdiction over interstate transmission and wholesale electricity sales, while states retain authority over generation facilities, retail rates, and decisions about resource mix. The D.C. Circuit has regularly been called upon to “referee the Federal Power Act’s jurisdictional line separating [FERC’s] jurisdiction over the federal wholesale market and States’ jurisdiction over facilities used in local distribution.”1 Read the full story...
Reprinted courtesy of Ryan J. Regula, Snell & Wilmer
Mr. Regula may be contacted at rregula@swlaw.com

VARINA IOWA CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES