Miller County Georgia Construction Expert Witness Directory

Credibility Matters…Even in Delay Claims

September 29, 2026 — David Adelstein - Florida Construction Legal Updates
Credibility matters. Here’s another example involving a delay claim on public private partnership delivery method. The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Late Notice Bars Insured’s Claim for Wind Damage

June 29, 2026 — Tred R. Eyerly - Insurance Law Hawaii
The court found that a six-month delay in reporting damage from wind did not comply with the policy’s notice requirements. Touchmark Hotel Group, LLC v. Mt. Hawley Ins. Co., 2026 U.S. Dist. LEXIS 61910 (S.D. N. Y. March 24, 2026). A storm caused damage to Touchstone’s hotel on January 4, 2023. Touchstone’s corporate representative, Rohit Patel, testified that he was not at the property on the day of the storm. In a telephone call the next day, the manager of the property reported to Patel that he observed detached shingles from the roof the hotel in the parking lot. Patel testified that he did not file a claim at that time because Touchmark’s employees did not detect any water leakage in the building and because he did not believe that the cost of the damage from the storm would exceed the policy’s deductible. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Differing Site Conditions Claim Requires a Misrepresentation

May 14, 2026 — David Adelstein - Florida Construction Legal Updates
If you are entertaining a differing site conditions claim, consider this Third District Court of Appeals case from the mid-90s. In Hendry Corp. v. Metropolitan Dade County, 648 So.2d 140 (Fla. 3d DCA 1995), a contractor was hired by Dade County to demolish the old Rickenbacker Causeway in Miami. The original 1941 plans of the causeway were made available to contractors. The lowest bidding contractor that was awarded the project based its bid “on its conclusion that the pilings supporting the old bridge were made of concrete.” Hendry, supra at 141. The contractor based this conclusion on the original plans, its visual observation, and experience. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Steel Cooling: Steel Costs Steadily Decline After Pandemic Price Shock

May 12, 2026 — Construction Executive
Steel prices have continued trending downward after several years of volatility, according to Gordian’s latest analysis based on RSMeans Data. After dramatic spikes during the pandemic-era supply disruptions, the market has gradually stabilized as supply chains improve and demand softens in some construction segments. However, selective volatility and tariff uncertainty continue to influence pricing across the sector. Key findings from the report include:

Steel prices declining: The national average price of structural steel fell to about $2,343.93 per ton in January 2026, down 5.38% from the previous quarter and 7.18% year over year.
Longer-term price correction: Steel costs have been trending downward since 2024 after earlier volatility driven by inflation, supply shortages and global demand swings.

Predict Risk, Not Incidents: A New Analytics Framework for Your Construction Safety Data

August 03, 2026 — Tabrez Zahoor - Construction Executive
Behind every “zero-incidents” company report, hidden hazards may already be accumulating—risks that could become serious injuries tomorrow. The question every executive should be asking is not, “Did anything go wrong last month?” It is: “Where is risk building on my projects right now?” Most construction organizations cannot answer that question. Not because the data does not exist—it does. Every active project generates daily inspection findings, labor records, near-miss reports and audit results. The problem is that standard safety systems collect this data and then report it in ways that make it operationally useless for prevention. They describe the past. They predict nothing. The predictive safety analytics framework (PSAF) is a practical, deployable system developed from years of applying data science to large-scale construction portfolio operations that takes the safety data construction organizations already collect and transforms it into a forward-looking risk signal. The result? A single weekly score that tells executives where risk is concentrating across their portfolio before anyone gets hurt. Reprinted courtesy of Tabrez Zahoor, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

Lost in Translation: AEC Tech’s Missing Role

May 12, 2026 — Aarni Heiskanen - AEC Business
I once visited a construction site where the contractor’s headquarters had commissioned a tech company to build an on-site quality-inspection application. The developer had admitted to the site engineer that they had never set foot on a construction site before. The engineer showed me what he was actually using: his own phone camera and an Excel sheet. The new app did not map to how work actually happened on site. This is not an isolated story. The vendor builds something technically coherent but operationally disconnected. The client, somewhere up the chain, had fallen in love with the idea of the solution before anyone had built an honest business case for it. The result is a tool that gets demonstrated at a board meeting but isn’t used in the field. Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Insurer Cannot Raise Issues on Appeal that Were Not Presented to the Trial Court

June 15, 2026 — Tred R. Eyerly - Insurance Law Hawaii
The Florida Court of Appeals affirmed a judgment on a collapse claim for the insured, rejecting the insurer’s arguments that were not presented to the trial court. Homeowner’s Choice Prop. & Cas. Ins, Co. v. Oakes, 2026 Fl. App. LEXIS 2086 (Fl. Ct. App. March 18, 2026). The insured’s ceiling collapsed in the secondary home on the insured’s property. The claim was reported to the insurer, but coverage was denied after its investigation. The insured sued the insurer for breach of contract. Under the Additional Coverage provisions of the policy, collapse was covered if it was “abrupt.” An abrupt collapse was not covered, however, if exclusions for “Fungi, Wet or Dry Rot” and “faulty, inadequate or defective design, specifications, workmanship, repair, construction, renovation, remodeling, materials or maintenance” applied. The collapse provisions contained no language stating that the coverage granted in the provision was also subject to all the other exclusions in the policy. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Traub Lieberman Recognized in the 2026 Edition of Chambers USA

June 29, 2026 — Traub Lieberman
In the 2026 edition of Chambers USA, Traub Lieberman has been awarded rankings in the following categories: Illinois – Insurance: Dispute Resolution: Insurer In the Chambers research, clients noted: "The team are technically very strong, responsive, and on top of their cases." Florida – Insurance: Dispute Resolution: Insurer In the Chambers research, clients noted: "Traub Lieberman Straus & Shrewsberry distinguishes itself through a combination of deep subject-matter expertise, responsiveness, and practical risk-management orientation." Commenters went on to say: “The team has deep knowledge of Florida property insurance statutes, regulations and case law, enabling effective handling of disputes, appeals and third-party litigation." Read the full story...
Reprinted courtesy of Traub Lieberman

MILLER COUNTY GEORGIA CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES