Clarkston Georgia Construction Expert Witness Directory

Lewis Brisbois Welcomes Clients and Community Leaders to New Garden City Office Opening

July 27, 2026 — Lewis Brisbois
On July 15, Lewis Brisbois hosted a ribbon-cutting event for its new Garden City office, which opened in April to serve the Long Island community and beyond. The event was attended by more than 100 people, including Lewis Brisbois attorneys and staff as well as clients, local business and government leaders, Nassau County Supreme Court judges, and members of the press. Nassau County Executive Bruce Blakeman delivered remarks and cut the ribbon for the office. Read the full story...
Reprinted courtesy of Lewis Brisbois

Traub Lieberman Wins Affirmation of Judgment on Pleadings Before the Seventh Circuit

August 16, 2026 — Dana A. Rice & Adam P. Joffe - Traub Lieberman
Traub Lieberman Partners Dana Rice and Adam Joffe obtained affirmation of judgment from the Seventh Circuit Court of Appeals in favor of an Insurance Company. The Insurance Company filed suit seeking a declaration that it had no duty to defend or indemnify its Insured, a Roofing Contractor, in an underlying lawsuit. The Insurance Company issued a commercial general liability policy with a one-year policy term. The policy included an exclusion that barred coverage for any losses arising out of work the insured completed before the date the policy incepted. Reprinted courtesy of Dana A. Rice, Traub Lieberman and Adam P. Joffe, Traub Lieberman Mr. Rice may be contacted at drice@tlsslaw.com Mr. Joffe may be contacted at ajoffe@tlsslaw.com Read the full story...

Moving in Before Substantial Completion? The Risks of Early Owner Occupancy

March 24, 2026 — Sydney Koby - ConsensusDocs
Introduction On many construction projects, particularly large projects facing schedule pressure, owners may begin occupying or using portions of the project before the work reaches substantial completion. This is often due to operational needs, phased turnover, or market demands that drive owners to take possession of all or part of a project while construction activities are ongoing. While early occupancy may seem practical, it can blur the lines of responsibility between owner and contractor and can create significant legal and practical complications. These disputes are especially common on large, complex projects where punch list work, system commissioning, and closeout activities overlap with owner use. Without clear documentation and carefully drafted contract provisions, early occupancy can undermine an owner’s ability to enforce completion requirements while simultaneously exposing the contractor to claims of delay, inefficiency, or interference. Read the full story...
Reprinted courtesy of Sydney Koby, Jones Walker
Ms. Koby may be contacted at skoby@joneswalker.com

The Who/What/How of Sealing Plans for Architects and Engineers (Law Note)

March 03, 2026 — Melissa Dewey Brumback - Construction Law in North Carolina
The proper use of professional seals in North Carolina is critical. Failure to follow the prescribed requirements can subject you or your Firm to a Board sanction. Did you know that the NC Board of Architecture and the NC Engineering Board have jointly prepared a fairly straightforward document that can tell you exactly what you need to know about sealing of plans? That document, the “Seal Brochure” (pdf) is available for download. Every state’s regulations are a little different (thank you Federalism!) so it is worth reviewing with your staff at regular intervals, especially if you do work across state lines. Read the full story...
Reprinted courtesy of Melissa Dewey Brumback, Ragsdale Liggett PLLC
Ms. Brumback may be contacted at mbrumback@rl-law.com

Additional Insureds Owed a Defense in Underlying Personal Injury Suit

March 03, 2026 — Tred R. Eyerly - Insurance Law Hawaii
The court granted partial summary judgment on the duty to defend to two additional insureds who were named as defendants in the underlying personal injury suit. In re Third St. Equity, LLC, 2025 U.S. Dist. LEXIS 234909 (E.D. N. Y. Dec. 2, 2025). Third Street Equity LLD hired Developing NY State, LLC as the contractor for a construction project. Developing NY entered a subcontract agreement with Capital Source Concrete NY LLC for concrete work as well as labor and services for a construction project. The subcontract required that Capital Concrete keep the construction site free of debris, waste material or rubbish. Further, Capital Concrete was responsible for compliance with OSHA safety regulations. It was also agreed that Capital Concrete would obtain liability and workers compensation insurance naming Third Street and Developing NY as additional insureds. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Standing When It Comes to Real Property Owned by a Trust

February 23, 2026 — David Adelstein - Florida Construction Legal Updates
It is not uncommon for property to be owned in the name of the trust as part of an estate planning agenda. In construction, improvements are made all the time to real property owned in the name of a trust or later transferred to a trust for estate planning purposes. In a recent case, the question became that if the property is owned by the trust does only the trust have standing to file the lawsuit. In this case, homeowners, in their individual capacities, sued a flooring contractor for defective work; however, prior to the lawsuit, the homeowners deeded the home (which would include the flooring in the home) to a revocable trust. The plaintiffs, though, were the trustees of the revocable trust and the settlors of the trust. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Project Labor Agreements: A New Bid Protest Forum Split

May 14, 2026 — Dirk D. Haire, David P.J. Timm and Michael J. Brewer - ConsensusDocs
Advertisements often include a disclaimer: “individual results may vary.” Similarly, lawyers are notorious for saying “it depends.” The mandatory Project Labor Agreement (“PLA”) regulations have recently placed into context this adage as it applies to federal contract bid protests, with very different results depending on which forum – the Court of Federal Claims (“COFC”) versus the Government Accountability Office (“GAO”) – different contractors have selected to bring PLA bid protests. Over the last two years, over 30 protesters have successfully achieved removal of mandatory PLAs from large-scale federal construction contracts based on two landmark bid protest decisions issued by the COFC. Similar challenges to PLAs at the GAO, however, have not been successful in removing PLAs, highlighting an emerging trend that the COFC is often a more effective relief forum than GAO for government construction contractors. Reprinted courtesy of Dirk D. Haire, Burr & Forman LLP, David P.J. Timm, Burr & Forman LLP and Michael J. Brewer, Burr & Forman LLP Mr. Haire may be contacted at dhaire@burr.com Mr. Timm may be contacted at dtimm@burr.com Mr. Brewer may be contacted at mbrewer@burr.com Read the full story...

Court to General Contractor: Too Late to Reclaim $600K Sub Overpayment

March 03, 2026 — Richard Korman - Engineering News-Record
Massachusetts contractors and their attorneys are once again testing the limits of the state's 15-year-old prompt-pay law, with concerned prime contractors asking an appeals court to overturn a lower court ruling that they believe gives subcontractors a powerful upper hand in payment disputes. Read the full story...
Reprinted courtesy of Richard Korman, Engineering News-Record
Mr. Korman may be contacted at kormanr@enr.com

CLARKSTON GEORGIA CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES