Zamora California Construction Expert Witness Directory

Achieving Sustainability Through Design-Build Delivery: Part I – An Overview

September 21, 2026 — Joshua M. Pruett, Jennifer L. Harris & Tiffany A. Harrod - Peckar & Abramson, P.C.
This article was written for the AGC’s Law in Brief and first appeared here. Sustainability is no longer optional. What was once a matter of public policy or corporate preference has become a regulatory mandate and is reshaping how construction projects are designed, built, and operated. This mandate is not solely figurative. Rather, states have started to follow Europe’s lead by beginning to codify sustainability requirements into regulations and law. California led the charge by adding mandatory embodied-carbon emissions regulations into CALGreen, and other states, such as New York, have introduced bills to implement similar requirements. Owners, designers, and builders must now treat sustainability not as aspirational, but as a clearly defined contract issue from the outset, particularly where the project is expected to achieve a third-party rating, meet energy or resiliency targets, qualify for incentives, or comply with evolving green building codes. In the federal public sector, construction contracts include a layered compliance framework—executive order-inspired policy, FAR-mandated clauses, and enduring statutory requirements—requiring contractors to integrate sustainability into design, material selection, and lifecycle management. Staying ahead means aligning with regulatory standards, conducting life-cycle cost analyses, and embedding sustainability into every procurement and construction decision. Reprinted courtesy of Joshua M. Pruett, Peckar & Abramson, P.C., Jennifer L. Harris, Peckar & Abramson, P.C. and Tiffany A. Harrod, Peckar & Abramson, P.C. Mr. Pruett may be contacted at jpruett@pecklaw.com Ms. Harris may be contacted at jharris@pecklaw.com Ms. Harrod may be contacted at tharrod@pecklaw.com Read the full story...

Are “Financial Hardship” Damages Recoverable?

June 08, 2026 — David Adelstein - Florida Construction Legal Updates
In a case out of the Civilian Board of Contract Appeals, F.O.G., LLC v. Department of the Interior, CBCA 8203, 2026 WL 1191881 (CBCA 2026) a contractor claimed damages that included “financial hardship” damages due to slow payments. The financial hardship damages included personal damages to the contractor’s president and his wife. Are these damages recoverable? Drumroll…The Board ruled that the contractor cannot recover such financial hardship damages. As it relates the personal financial hardship damages, the Board ruled, “Neither [the contractor’s] president nor his wife are a party to this contract, are in privity of contract with [the government], or are the beneficiaries under this contract. [The contractor], therefore, cannot recover for any losses that either one has suffered individually and that [the contractor] claimed in this appeal.” F.O.G., LLC, supra. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Insureds’ Altering Dates for Hailstorm Damage Justifies Denial of Claim

June 02, 2026 — Tred R. Eyerly - Insurance Law Hawaii
The Firth Circuit affirmed the district court’s grant of summary judgment to the insurer due to the insureds’ failure to establish the date of loss after a hailstorm. Cutchall v. Chubb Lloyds Ins. Co. of Texas, 2026 WL 625633 (5th Cir. March 5, 2026). In September 2021, the Cutchalls made a claim on their policy for interior water damage due to a hailstorm that breached their roof. Chubb retained two engineers to inspect the home, but neither found evidence that a hailstorm caused the damage. Instead, the engineers concluded a variety of other causes, such as poor ventilation and as-built defects, caused the damage. Because Chubb concluded that some of these other causes were covered by the policy, it paid only for the covered portions. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

One Industry, One Goal: Construction Safety Week 2026

May 05, 2026 — Maggie Murphy - Construction Executive
Construction safety has long been a top priority across the industry. Yet fatality rates have remained stubbornly flat for more than a decade. Steven Carter, global health and safety director at Gilbane chair company for Construction Safety Week 2026—believes the industry has reached a pivotal moment. This year’s theme—”All In Together: Recognize. Respond. Respect.”—is a unified call to action for owners, designers, contractors and craft professionals around a shared, risk-based approach to preventing serious injuries and fatalities. In a recent interview with Construction Executive, Carter discusses why the industry must move beyond incremental improvements, how technology and AI can support better planning and what it will take to create a true culture of psychological safety on jobsites. Reprinted courtesy of Maggie Murphy, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

Congratulations to Gianna Liddy on Her Promotion to Partner

September 21, 2026 — Dolores Montoya - Bremer Whyte Brown & O’Meara, LLP
Bremer Whyte Brown & O’Meara, LLP is proud to announce that Gianna Liddy has been promoted to partner. Gianna’s dedication, leadership, and exceptional contributions to the firm have earned her this well-deserved recognition. Please join us in congratulating her on this exciting achievement! Meet Gianna Liddy! Gianna has been with BWB&O since 2019 and has been practicing law since 2017. Her practice focuses on complex civil defense litigation, including high-exposure personal injury, premises liability, transportation, construction defect, habitability, and general liability matters. As a Supervising Attorney in the firm’s Encinitas office, she oversees a team of attorneys, collaborates closely with clients and insurance professionals, and develops litigation strategy in complex matters. Read the full story...
Reprinted courtesy of Bremer Whyte Brown & O’Meara, LLP

Credibility Matters…Even in Delay Claims

September 29, 2026 — David Adelstein - Florida Construction Legal Updates
Credibility matters. Here’s another example involving a delay claim on public private partnership delivery method. The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

373 Snell & Wilmer Attorneys Recognized in the 2027 Edition of The Best Lawyers in America®

October 06, 2026 — Snell & Wilmer
PHOENIX – Snell & Wilmer is pleased to announce that 373 of the firm’s attorneys were recently selected by their peers for inclusion in the 2027 edition of The Best Lawyers in America® including the prestigious “Lawyer of the Year” honors, and “Ones to Watch” list. Attorneys listed as Ones to Watch typically have been in practice for five to nine years. “Lawyer of the Year” recognition is awarded to individual lawyers with the highest overall peer-feedback for a specific practice area and geographic region. Only one lawyer is recognized for each practice area and location. The following Snell & Wilmer attorneys were named 2027 “Lawyer of the Year” award recipients: Cortland P. Andrews, Troy J. Aramburu, Brian L. Blaylock, M. Lawrence Brown, Brian D. Cunningham, Michael M. Donahey, Jason Ebe, Matthew P. Fischer, Brett W. Johnson, Nathan G. Kanute, William A. Kastin, Timothy J. Kay, James D. Kilroy, Joseph A. Kroeger, Matthew L. Lalli, John F. Lomax, Anne M. Meyer, Robin L. Miskell, Patrick J. Paul, Amit D. Ranade, and M. Roxanne Veliz. Read the full story...
Reprinted courtesy of Snell & Wilmer

Managing Rising Costs and Shifting Legal Risk for Florida High-Rise and Condominium Projects

May 05, 2026 — Stephen Hauptman - Ball Janik LLP
Florida's construction defect landscape is experiencing a major shift. The convergence of material and labor cost volatility, regulatory tightening, and increasingly complex litigation strategies is forcing associations, developers, and their counsel to rethink how they approach risk management and dispute resolution. For those managing large-scale condo and high-rise projects, the stakes have never been higher. The Cost Volatility Trap Construction material prices rose at a "staggering" 12.6% annualized rate during the first two months of 2026, according to recent industry analysis. Tariff impacts are projected to lead to more increases of 5.4% to 6.8%, depending on property type. For associations facing construction defect claims, this volatility creates a cascading problem: repair scopes defined two years ago are now dramatically underpriced, and damage calculations that appeared reasonable at discovery are obsolete by the time of settlement. Courts and mediators are increasingly scrutinizing how cost estimates were developed and whether they account for existing market circumstances. Associations must now commission updated repair assessments more frequently, a practice that increases investigation costs but strengthens the credibility of damage claims. Conversely, defendants are weaponizing cost inflation as a defense, arguing that claimed damages are speculative or inflated. The practical result: repair sequencing and phasing strategies have become critical litigation tools. Associations that can demonstrate a rational, cost-effective repair plan tied to current market data are more favorably placed in settlement negotiations. Regulatory Pressure and Deliberate Timing Florida's 2026 condo compliance regime has significantly changed the defect claims landscape. Elevated transparency requirements, stricter reserve funding mandates, and tightened building safety inspection protocols mean that associations now face dual pressures: Comply with new regulations while simultaneously handling construction defect exposure. This regulatory environment is changing investigation and documentation strategy. Associations that delay defect investigation to avoid triggering reserve funding obligations or disclosure requirements are taking on considerable legal risk. Recent case law such as the Third District Court of Appeal's reaffirmation of Chapter 558's pre-suit mediation requirements, underscores Florida's intent to resolve disputes early. Associations that move deliberately and record carefully during the pre-suit phase gain leverage in mediation and reduce the risk of expensive litigation. Timing also intersects with repair sequencing. Associations must now balance the urgency of compliance inspections against the strategic advantage of phased repairs. Some associations are using compliance deadlines as a forcing mechanism to accelerate settlement discussions, while others are sequencing repairs to demonstrate good-faith remediation efforts before litigation commences. The Emerging Risk Transfer Challenge As construction defect claims grow more complex and costly, the traditional risk transfer systems, such as design-build warranties, contractor bonds, and insurance, are proving inadequate. Developers and general contractors are increasingly shifting risk to subcontractors and material suppliers, fragmenting liability and complicating recovery efforts for associations. Permitting and approval friction is also creating new litigation pressure points. Delays in municipal approvals, changes to building code interpretations, and disputes over remedial work compliance continue to spawn collateral claims that go beyond the original defect. Associations must now anticipate not only defect liability but also regulatory compliance disputes with municipalities, creating a dual-front legal challenge. For large communities, this means reconsidering the entire risk architecture. Insurance carriers are tightening coverage, and traditional indemnification chains are breaking down. Forward-thinking associations are engaging counsel earlier in the development process to negotiate clearer risk allocation provisions and more robust insurance requirements. Taking a Data-Driven Approach Managing rising costs and shifting legal risk in Florida's high-rise and condo market requires a more sophisticated, data-driven approach. Associations must commission frequent cost updates, move deliberately through pre-suit investigation and mediation, and challenge traditional assumptions about risk transfer. Developers and their counsel should view regulatory compliance not as a burden but as an opportunity to demonstrate good-faith risk management and strengthen settlement positioning. The firms and associations that succeed in 2026 will be those that treat cost volatility, regulatory change, and litigation strategy not as separate challenges but as linked elements of a coherent risk management framework. Stephen Hauptman is special counsel in Ball Janik LLP’s Fort Lauderdale office. He may be reached at shauptman@balljanik.com.

ZAMORA CALIFORNIA CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES