Caldwell Arkansas Construction Expert Witness Directory

Credibility Matters…Even in Delay Claims

September 29, 2026 — David Adelstein - Florida Construction Legal Updates
Credibility matters. Here’s another example involving a delay claim on public private partnership delivery method. The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Vacant Building Negates Coverage for Broken Pipe

September 01, 2026 — Tred R. Eyerly - Insurance Law Hawaii
The Michigan Court of Appeals found the insured was not covered for water damage because the commercial space was left vacant. Cherry Hill Recreation Center, Inc. v. Conifer Ins Co., 2026 Mich, App. LEXIS 5099 (Mich Ct. App. June 18, 2026). Alan Abbas purchased a bowling alley. Due to the onset of the COVID-19 pandemic and executive orders issued by the governor, Abbas was unable to operate the bowling center for several months. During the winter, Abbas allowed the thermostat to drop significantly, with the building expected to be around 43 degrees Fahrenheit. He later admitted the sprinkler system’s pipes were not protected against freezing. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Wisconsin Supreme Court Finds Coverage Under Ensuing Loss Provisions

September 29, 2026 — Tred R. Eyerly - Insurance Law Hawaii
Reversing the trial court’s grant of summary judgment to the insurer, the Wisconsin Supreme Court determined that genuine issues of material fact existed on whether ensuing losses as defined in the policy were covered. Cincinnati Ins. Co. v. Ropicky, 2026 Wisc. LEXIS 302 (Wis. July 7, 2026). The insured suffered damage during a storm on May 11, 2018, when rainwater poured into the home. The insureds gave notice to their insurer, Cincinnati. Upon inspection, Cincinnati determined that water intrusion resulted from multiple construction defects in the home. In the front of the home, water entered through a gap in the stone veneer. The inspector also concluded that the damage from rainwater was not just from the May 11, 2018, storm, but damage had occurred from prior storm events. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Generic Complaint Alleging Bad Faith is Insufficient

August 24, 2026 — Tred R. Eyerly - Insurance Law Hawaii
The federal district court granted the insurer’s motion for judgment on the pleadings after determining that the insured’s claims for bad faith and unfair claims settlement practices were insufficiently pled. Navia v. State Farm Fire & Cas. Co., 2026 U.S. Dist. LEXIS 111261 (W.D. N. C. May 20, 2026). The insured submitted a claim for damages to real property owned by the insured allegedly caused by Hurricane Helene. State Farm advised the insured that only some of the claimed damages were covered by the policy and payment for such damages were denied because the estimate for the covered damages did not exceed the policy’s deductible. The insured sued asserting claims for breach of contract, bad faith, and unfair claim settlement practices. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Federal Court Highlights the Strategic Value of Additional Insured Coverage

June 22, 2026 — Michael S. Levine - Hunton Insurance Recovery Blog
A recent decision from the District of Maryland underscores a recurring—but often underutilized—opportunity for policyholders: securing and enforcing additional insured coverage under another party’s liability policy. In Charter Oak Fire Insurance Co. v. Builders Premier Insurance Co., the court held that an equipment lessor qualified as an additional insured under the lessee’s policy and was entitled to a primary defense. The decision is a useful reminder that additional insured coverage can fundamentally shift defense obligations and materially reduce a policyholder’s exposure. We build on the decision to highlight the practical steps policyholders should take to ensure that all potentially available insurance is identified and pursued. Read the full story...
Reprinted courtesy of Michael S. Levine, Hunton Andrews Kurth LLP
Mr. Levine may be contacted at mlevine@hunton.com

PJM’s Reliability Backstop Procurement Proposal—Fast-Track Capacity to Meet Rising Large-Load Demand

May 12, 2026 — Stephen J. Humes, Alicia M. McKnight, Jason Drogin Atwood & Andrew H. Jacobs - Gravel2Gavel
In January, we discussed the Statement of Principles jointly signed by the National Energy Dominance Council and governors across the mid-Atlantic region—framing accelerating demand (especially from large-scale data centers) as an emergency reliability issue for PJM Interconnection, L.L.C. (PJM), the nation’s largest power grid operator. That policy signal is now becoming a near-term, accelerated procurement and contracting exercise. On April 8, 2026, PJM notified stakeholders of a critical issue fast path reliability backstop procurement process. PJM subsequently released a request for information (RFI) with respect to a proposed Reliability Backstop Procurement (RBP)—a one-time mechanism intended to attract significant new capacity to address projected reliability shortfalls driven by large-load growth. RBP compresses what is often a multiyear market and regulatory conversation into a fast-moving set of commercial choices. Developers, large loads, utilities and capital providers should be preparing now for (i) an accelerated bilateral contracting window and (ii) a standardized PJM-led backstop procurement if bilateral deals do not clear enough capacity. Reprinted courtesy of Stephen J. Humes, Pillsbury, Alicia M. McKnight, Pillsbury, Jason Drogin Atwood, Pillsbury and Andrew H. Jacobs, Pillsbury Mr. Humes may be contacted at stephen.humes@pillsburylaw.com Ms. McKnight may be contacted at alicia.mcknight@pillsburylaw.com Mr. Atwood may be contacted at jason.atwood@pillsburylaw.com Mr. Jacobs may be contacted at andrew.jacobs@pillsburylaw.com Read the full story...

Navigating Timelines and Technology: Patent Strategies for Space and Earth

June 01, 2026 — Kate Nuehring Su & Vanessa Wang - Engineering News-Record
More than half a century after the Apollo 11 landing fulfilled President John F. Kennedy’s bold vision, the global race back to the Moon is no longer theoretical. With renewed attention on NASA’s Artemis program and a surge of commercial investment in space infrastructure, lunar exploration is again shaping technology priorities here on Earth. Reprinted courtesy of Kate Nuehring Su, Engineering News-Record and Vanessa Wang, Engineering News-Record Read the full story...
ENR may be contacted at enr@enr.com

Legal 500 US Ranks Hunton’s Insurance Coverage Team Among Top Policyholder Practices in 2026 Guide

July 06, 2026 — Hunton Insurance Recovery Blog
Hunton’s insurance coverage practice was once again recognized among the nation’s top policyholder insurance practices, receiving a Band 2 national ranking in the 2026 United States Edition of The Legal 500 for Insurance: Advice to Policyholders. The Legal 500 recognizes firms solely based on merit through numerous factors including client feedback and peer input. Bolstering the team’s national recognition, several coverage lawyers received individual accolades: special counsel Lorelie “Lorie” S. Masters was named to The Legal 500’s Hall of Fame; team head Syed S. Ahmad and partner Michael S. Levine were named Leading Lawyers; and partners Andrea DeField and Latosha M. Ellis were named Next Generation Partners. In addition, partners Walter J. Andrews, Lawrence J. Bracken II, and Koorosh “KT” Talieh were recognized as Key Lawyers on the team. Read the full story...
Reprinted courtesy of Hunton Andrews Kurth LLP

CALDWELL ARKANSAS CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES