The Plains Ohio Construction Expert Witness Directory

Insurer Dispenses with Bad Faith Claim on Summary Judgment

June 22, 2026 — Tred R. Eyerly - Insurance Law Hawaii
The court granted the insurer’s motion for partial summary judgment because the insured failed to present evidence that the insurer failed to conduct a reasonable investigation. PSY Burger, LLC v. State Farm General Insurance Company, 2026 U.S. Dist. LEXIS 66991(C.D. Cal. March 20, 2026). The insured’s commercial property suffered heavy damage from tropical storm Hilary. State Farm denied coverage to repair the damage. The insured sued State Farm alleging breach of contract and bad faith due to an inadequate investigation. Apparently, the insured did not retain an expert to opine on claims handling. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Additional Insureds Obligated to Meet Self-Insured Retention

October 20, 2026 — Tred R. Eyerly - Insurance Law Hawaii
The federal district court found that the additional insureds had to meet the policy’s self-insured retention before a duty to defend was triggered. Amerisure Ins. Co. v. Premier Design & Build Group, LLC, 2026 U.S. Dist. LEXXIS 170741 (N.D. Ill. July 31, 2026). Amerisure issued CGL and umbrella policies to Premier Design & Build Group, LLC. Amerisure had the right and duty to defend in certain suits for property damage under both policies. Premier contracted with MG East, LLC (MGE) to build three buildings. After the buildings were constructed, MG filed suit against Premier in state court, seeking recovery for allegedly defective installation of the roof, flashing, and gutters on each of the buildings. Premier had subcontracted with Tecta American Sough Florida, Inc. to install the flashing. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

GRSM Team Obtains Defense Verdict for Homeowners’ Association in Orange County Superior Court

July 20, 2026 — Gordon Rees Scully Mansukhani
A Gordon Rees Scully Mansukhani multi-state team, including Partners Christine Barker, Sean Ferron, and Keith Cramer, obtained a defense verdict on behalf of a homeowners’ association (HOA) in an Orange County Superior Court bench trial spanning two months. The case began in 2022 when a homeowner sued after the Architectural Review Committee and HOA Board of Directors declined his teardown-and-rebuild plans due to view and aesthetic concerns. After a motion for summary judgment ruling in which the court found that the existing covenants, conditions, and restrictions (CC&Rs) did not protect views, the HOA held a special election to add explicit view protections to the CC&Rs. At the February 2025 trial call, the plaintiff sought leave to file a third amended complaint challenging the validity of that vote, drastically reframing the case from CC&R enforcement to one of election validity. A second plaintiff then filed a parallel action toward the end of the limitations period, and the two cases were consolidated. Read the full story...
Reprinted courtesy of Gordon Rees Scully Mansukhani

New York Orders Moratorium on Large Data Center Permits

July 27, 2026 — Levi W. Barrett - Peckar & Abramson, P.C.
Levi W. Barrett, Co-Managing Partner of Peckar & Abramson’s New Jersey office, Co-Chair of the firm’s Construction Contracts & Risk Management team, and Executive Committee Member, was recently quoted in “New York Orders Moratorium on Large Data Center Permits,” an article written by Engineering News-Record (ENR). The article examines New York Governor Kathy Hochul’s executive order temporarily halting state environmental permit reviews for certain large-scale data center projects while regulators develop a comprehensive framework to address the sector’s energy demands, water consumption, environmental impacts, and effects on local communities. It also explores the broader implications of the moratorium for developers, contractors, investors, and other stakeholders, as well as the ongoing debate between economic development, AI-driven infrastructure growth, and environmental and utility ratepayer concerns. Read the full story...
Reprinted courtesy of Levi W. Barrett, Peckar & Abramson, P.C.
Mr. Barrett may be contacted at lbarrett@pecklaw.com

Credibility Matters…Even in Delay Claims

September 29, 2026 — David Adelstein - Florida Construction Legal Updates
Credibility matters. Here’s another example involving a delay claim on public private partnership delivery method. The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

11 Payne & Fears Attorneys Honored by Best Lawyers

August 24, 2026 — Payne & Fears
Congratulations to the 11 Payne & Fears attorneys included in the 2027 Edition of “Lawyer of the Year” and The Best Lawyers In America®. Attorneys have been recognized in the following practice areas: “Lawyer of the Year” (2027 Edition) Orange County

Benjamin A. Nix

Trade Secrets Law

The Best Lawyers in America® (2027 Edition) Irvine, CA

Jeffrey K. Brown

Employment Law – Management
Labor Law – Management
Litigation – Labor and Employment

Daniel F. Fears

Employment Law – Management
Labor Law – Management
Litigation – Labor and Employment

Daniel M. Livingston

Commercial Litigation
Litigation – Real Estate

Read the full story...
Reprinted courtesy of Payne & Fears

Bad Faith Claim Survives Summary Judgment

June 08, 2026 — Tred R. Eyerly - Insurance Law Hawaii
The court denied the insurer’s motion for partial summary judgment on the insured’s bad faith claim, but granted the motion on the insured’s claim for punitive damages. Serbian Orthodox Church v. Brotherhood Mut. Ins. Co., 2026 U.S. Dist. LEXIS 58234 (S.D. Cal. March 19, 2026). On February 1, 2023, the Church filed a claim for water damage with Brotherhood Mutual Insurance Company (BMIC). The claim was based on rain and wind that caused extensive water intrusion into the Sanctuary, damaging its plaster walls and ceilings and fresco paintings. The claim was assigned to Patrick Hurley. Hurley sent a letter discussing potential bars to coverage and requesting further information and documents from the Church. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Celebrating Freedom: The Overlooked Freedom to Contract in Commercial Insurance

July 20, 2026 — Michael S. Levine & Andrea DeField - Hunton Insurance Recovery Blog
Happy 4th and 250 years of freedom . . . to contract! Many policyholders assume insurance policies are “standard” and must be accepted as-is. That assumption is often wrong—and dangerously limiting. Unlike many consumer insurance markets, the commercial insurance realm preserves a robust “freedom to contract,” allowing sophisticated policyholders to negotiate terms, exclusions, definitions, and limits before a policy is even issued. Particularly in recent years, high-profile disputes over cyber coverage, business interruption, and war/cyber exclusions have shown not just what happens when coverage is denied, but what could have been done up front to avoid those fights. This post highlights the power policyholders still hold in the negotiation process and illustrates, with concrete examples from recent media-covered disputes, how that freedom can be strategically used. Reprinted courtesy of Michael S. Levine, Hunton Andrews Kurth LLP and Andrea DeField, Hunton Andrews Kurth LLP Mr. Levine may be contacted at mlevine@hunton.com Ms. DeField may be contacted at adefield@hunton.com Read the full story...

THE PLAINS OHIO CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES