Hauppauge New York Construction Expert Witness Directory

Federal Bid Protest Standard of Review and Disparate Treatment with Ratings

August 16, 2026 — David Adelstein - Florida Construction Legal Updates
A recent decision out of the Federal Claims Court explains the post-award bid protest standard of review. In Massman Construction Co. v. U.S., 2026 WL 1971985 (Fed.Cl. 2026), a protestor brought a post-award bid protest after the Army Corps of Engineers awarded the contract to another contractor. The protestor argued that the Army Corps (government) acted irrational in its evaluation through disparate treatment. The Court of Federal Claims agreed and remanded for the Army Corps to “either justify this disparity or explain why [awardee’s] lower-priced, but technically inferior proposal provides the best value to the government.” Massman Construction, supra at *1. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Credibility Matters…Even in Delay Claims

September 29, 2026 — David Adelstein - Florida Construction Legal Updates
Credibility matters. Here’s another example involving a delay claim on public private partnership delivery method. The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Predict Risk, Not Incidents: A New Analytics Framework for Your Construction Safety Data

August 03, 2026 — Tabrez Zahoor - Construction Executive
Behind every “zero-incidents” company report, hidden hazards may already be accumulating—risks that could become serious injuries tomorrow. The question every executive should be asking is not, “Did anything go wrong last month?” It is: “Where is risk building on my projects right now?” Most construction organizations cannot answer that question. Not because the data does not exist—it does. Every active project generates daily inspection findings, labor records, near-miss reports and audit results. The problem is that standard safety systems collect this data and then report it in ways that make it operationally useless for prevention. They describe the past. They predict nothing. The predictive safety analytics framework (PSAF) is a practical, deployable system developed from years of applying data science to large-scale construction portfolio operations that takes the safety data construction organizations already collect and transforms it into a forward-looking risk signal. The result? A single weekly score that tells executives where risk is concentrating across their portfolio before anyone gets hurt. Reprinted courtesy of Tabrez Zahoor, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

Traub Lieberman Attorneys Recognized in the 2027 Edition of The Best Lawyers in America®

September 08, 2026 — Traub Lieberman
Traub Lieberman is pleased to announce that four Partners have been selected by their peers for inclusion in the 2027 edition of The Best Lawyers in America®. In addition, six attorneys have been included in the 2027 Best Lawyers®: Ones to Watch list. These recognitions include attorneys from the firm’s White Plains, NY; Chicago, IL; Palm Beach Gardens, FL; and St. Petersburg, FL offices. 2027 Best Lawyers® White Plains, NY

Lisa L. Shrewsberry – Commercial Litigation

Chicago, IL

Brian C. Bassett – Insurance Law

Palm Beach Gardens, FL

Rina Clemens – Personal Injury Litigation – Defendants, Product Liability Litigation – Defendants

St. Petersburg, FL

Lauren S. Curtis – Insurance Law

Read the full story...
Reprinted courtesy of Traub Lieberman

Did You Know: Unique Legal Considerations for Animal Care Facilities

August 24, 2026 — Hannah Skidmore - Construction Executive
Animal care facilities are highly specialized environments that require expertise far beyond traditional commercial or even standard medical construction. Whether designing and building animal shelters, doggy daycares, veterinary clinics or full-service animal hospitals, these facilities operate under conditions that introduce unique challenges related to sanitation, durability, animal behavior and operational workflows. Because of these complexities, projects that fail to account for animal care requirements adequately often encounter costly issues—many of which result in litigation. Below are real-world examples drawn from expert witness work, followed by proactive best practices construction professionals should apply to future animal care projects. Reprinted courtesy of Hannah Skidmore, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

How AI Turns Construction Documents Into Procurement Intelligence

May 05, 2026 — Aarni Heiskanen - AEC Business
MEP equipment accounts for up to 40% of costs on data center or hospital projects, has lead times ranging from 20 weeks to over a year, and has historically been the most underserved area in construction software. In this episode, I speak with Victor Muchiri from BuildVision about what it actually takes to make AI useful in construction procurement, not as a pilot, but in production. We dig into why you cannot simply upload a set of construction drawings to ChatGPT and trust the output. Construction documents are complex, cross-referenced, and consequential. Without deep domain context, such as manufacturer ontologies, equipment taxonomies, and engineering expertise, AI produces plausible results, not reliable ones. BuildVision’s approach is to act as a harness around AI models, wrapping them in construction-specific knowledge so the output can be trusted for real procurement decisions. Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

EPA Expands PFAS Reporting Requirements with Addition of New Chemical to Toxics Release Inventory, Published by Law360

June 08, 2026 — Gordon Rees Scully Mansukhani
The U.S. Environmental Protection Agency’s (EPA) addition of sodium perfluorohexanesulfonate (PFHxS-Na) to the Toxics Release Inventory (TRI) introduces new federal reporting requirements for businesses that manufacture, process, or use the chemical. Because reporting obligations apply retroactively to the start of the year, affected facilities must quickly evaluate their compliance and recordkeeping practices. In a recent Law360 article, Gordon Rees Scully Mansukhani Senior Counsel, Ayodeji Ayolola, explains why PFHxS-Na was automatically added to the TRI, how the EPA’s public reporting system works, and which businesses may be affected by the new rule. The article also touches upon key compliance considerations, including supply chain reviews, reporting thresholds for chemicals of special concern, and preparation for public disclosure requirements. Read the full story...
Reprinted courtesy of Gordon Rees Scully Mansukhani

UPDATED: No Easy Fix for Potomac River Sewage Spill, Now Estimated at $20M

April 08, 2026 — Jim Parsons & Debra K. Rubin - Engineering News-Record
One month after a collapsed pipeline north of Washington, D.C., spilled about 240 million gallons of raw sewage into the Potomac River and possibly between 300 and 400 million—which could be the largest wastewater spill in U.S. history—efforts are progressing to clear the damaged section and begin repairs despite weather and other impacts. Reprinted courtesy of Jim Parsons, Engineering News-Record and Debra K. Rubin, Engineering News-Record Ms. Rubin may be contacted at rubind@enr.com Read the full story...

HAUPPAUGE NEW YORK CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES