Challenging Enforceability of Liquidated Damages (In Federal Construction Context)
March 11, 2024 —
David Adelstein - Florida Construction Legal UpdatesA recent summary judgment opinion from the Armed Services Board of Contract Appeals (ASBCA), Appeals Of – BCI Construction USA, Inc.,ASBCA No. 6257, 2024 WL 773324 (2024), contains a worthy discussion regarding a contractor’s challenge to the government’s assessment of liquidated damages, specifically the enforceability of the liquidated damages rate. Although this challenge is in the federal context, this discussion would be more expansive and apply outside of the federal context.
When dealing with the enforceability of a liquidated damages, the ASBCA “examines whether the liquidated damages amount ‘is extravagant, or disproportionate to the amount of property loss, as to show that compensation was not the object aimed at or as to imply fraud, mistake, circumvention or oppression.” Appeals of – BCI Construction USA, Inc. (citation omitted).
Read the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Competitive Bidding Statute: When it Applies and When it Does Not
April 15, 2024 —
Mason Fletcher - Ahlers Cressman & Sleight PLLCThe University of Washington (UW), a public university, aimed to secure a real estate developer for a new building on its campus. The proposal involved an 80-year ground lease (the “Lease”), and developers submitted bids. The selected developer would demolish an existing building, construct a new one, own it during the Lease at its own cost, and UW would lease back a portion, with ownership reverting to UW at the Lease’s end. Alexandria Real Equities, Inc. (ARE) was a finalist but ultimately was not selected, and the Lease was awarded to Wexford Science and Technology, LLC (Wexford). As a result, ARE filed suit against UW asserting three claims: 1) UW lacked authority to execute the Lease, 2) UW didn’t follow required competitive bidding procedures, and 3) UW’s developer selection process was arbitrary and capricious. None of these claims were successful and ARE appealed.
Division II of the Washington Court of Appeals affirmed in Alexandria Real Estate Equities Inc. v. Univ. of Wash., __ Wn. App. __, 539 P.3d 54 (2023), a published decision. The Court concluded, based on the facts in that case, that because construction was not publicly funded, UW did not have to follow competitive bidding requirements that were laid out in a statute relevant to state universities. Still, the Court applied the “bright-line cutoff point” that prohibits disappointed bidders from challenging an award once a contract has been executed. See Dick Enterprises, Inc. v. Metro. King County, 83 Wn. App. 566, 572, 922 P.2d 184 (1996).
Read the full story...Reprinted courtesy of
Mason Fletcher, Ahlers Cressman & Sleight PLLCMr. Fletcher may be contacted at
mason.fletcher@acslawyers.com
Real Estate & Construction News Roundup (09/06/23) – Nonprofit Helping Marginalized Groups, Life Sciences Taking over Office Space, and Housing Affordability Hits New Low
October 24, 2023 —
Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law BlogIn our latest roundup, Walmart adds their own generative AI, major airlines reduce their capacity at regional airports, autoworkers prepare for a strike as negotiations continue, and more!
Read the full story...Reprinted courtesy of
Pillsbury's Construction & Real Estate Law Team
An Architect Uses AI to Explore Surreal Black Worlds
October 24, 2023 —
Kriston Capps - BloombergFor architect Curry Hackett, the appeal of using artificial intelligence to design projects isn’t to build the world of the impossibly distant future. Instead he wants to mine the near present, using machine learning to generate postcards from a world that is recognizably our own, but refracted through a lens of Black history and material design.
Hackett is the designer behind a series of provocations made using AI to remix Black vernacular architecture in kaleidoscopic Afrofuturist landscapes. Specifically, he’s assembling images with Midjourney, an AI tool favored by architects to imagine what buildings might look like. Hackett’s prompts result in straightforward yet surreal sets, including roadside Popeyes kiosks in rural North Carolina, homes with inflatable porches in the Florida panhandle and park benches made out of the couch from grandma’s living room. Quilts, basket weaving and other cultural modes associated with American South are the building materials for Hackett’s speculative futures.
Read the full story...Reprinted courtesy of
Kriston Capps, Bloomberg
A New Lawsuit Might Change the Real Estate Industry Forever
December 23, 2023 —
Tracy Alloway, Joe Weisenthal, and Aashna Shah - BloombergLast month, a Missouri jury found that real estate brokers colluded to artificially inflate and fix their own commissions, and as a result, ordered the National Association of Realtors to pay $1.8 billion in damages. While the ruling will be appealed, with highly uncertain damages and remedies, the case is shining a light on how participants in the real estate industry get paid, and raising the question of whether homebuyers are paying too much to their brokers. So how do brokers get paid? What are their incentives? And why haven't fees for brokers gone down, even as online platforms that compete with them have proliferated. On this episode of the podcast, we speak with Andra Ghent, a finance professor at the University of Utah and a specialist in real estate who explains how the structure works currently, and how the lawsuit could ultimately change the entire business model of buying and selling homes. This transcript has been lightly edited for clarity.
Reprinted courtesy of
Tracy Alloway, Bloomberg,
Joe Weisenthal, Bloomberg and
Aashna Shah, Bloomberg Read the full story...
New Jersey Strengthens the Structural Integrity of Its Residential Builds
March 11, 2024 —
Matthew D. Stockwell - Gravel2Gavel Construction & Real Estate Law BlogIn response to the June 2021 Champlain Towers collapse in Florida, New Jersey supplemented its State Uniform Construction Code Act by enacting legislation (effective January 8, 2024) to strengthen laws related to the structural integrity of certain residential structures in the State. The legislation applies to condominiums and cooperatives (but not single-family dwellings or primarily rental buildings) with structural components made of steel, reinforced concrete, heavy timber or a combination of such materials. The legislation also supplements the Planned Real Estate Development Full Disclosure Act to ensure that associations created under the Act maintain adequate reserve funds for certain repairs.
The legislation requires structural engineering inspections of any primary load-bearing system (structural components applying force to the building which deliver force to the ground including any connected balconies). Buildings that are constructed after the date the legislation was signed must have their first inspection within 15 years after receiving a Certificate of Occupancy. Buildings that are 15 years or older must be inspected within two years of the legislation. Thereafter, the structural inspector will determine when the next inspection should take place, which will be no more than 10 years after the preceding inspection, except for buildings more than 20 years old which must be inspected every five years. Also, if damage to the primary load-bearing system is otherwise observable, an inspection must be performed within 60 days.
Read the full story...Reprinted courtesy of
Matthew D. Stockwell, PillsburyMr. Stockwell may be contacted at
matthew.stockwell@pillsburylaw.com
Traub Lieberman Partner Kathryn Keller and Associate Steven Hollis Secure Final Summary Judgment in Favor of Homeowner’s Insurance Company
April 02, 2024 —
Kathryn Keller & Steven A. Hollis - Traub LiebermanTraub Lieberman Partner Kathryn Keller and Associate Steven Hollis obtained summary judgment on behalf of a major homeowners’ insurer in a breach of contract action in the Ninth Judicial Circuit in and for Osceola County, Florida. The underlying claim involved a water loss in a bathroom of the Plaintiff’s property allegedly resulting in substantial damage to the home. The claim had been reported by Plaintiff’s counsel. The Plaintiff had retained counsel and two vendors before giving notice to the insurer. In addition, the insurer’s field adjuster was not provided the opportunity to inspect the plumbing parts that had been allegedly damaged. Specifically, the drainage system had been completely removed and replaced. The insurer retained an engineer, who concluded that the removal of the original plumbing components hindered the ability of the engineer to determine their conditions prior to removal. Meanwhile, the surface conditions of the white PVC pipe appeared bright and shiny as compared to other piping. The insured had also failed to provide a signed, sworn proof of loss within sixty days after the loss.
Reprinted courtesy of
Kathryn Keller, Traub Lieberman and
Steven A. Hollis, Traub Lieberman
Ms. Keller may be contacted at kkeller@tlsslaw.com
Mr. Hollis may be contacted at shollis@tlsslaw.com
Read the full story...
Gibbs Giden is Pleased to Announce Four New Partners and Two New Associates
January 08, 2024 —
Gibbs Giden Locher Turner Senet & Wittbrodt, LLPWe take great pleasure in announcing that
Richard Marks and
Kyle Marks have joined the firm. They bring a combined 60 years of real property law experience to Gibbs Giden. Well known Title Insurance and seasoned real estate attorneys they have both served as chair of the Title Insurance Subsection of the Los Angeles County Bar Association and are adjunct professors at Southwestern University School of Law. We are excited to welcome these two exceptional partners and their commitment to representing clients with honesty, integrity, and excellence. You can find them in our firm’s Westlake office.
Talented attorneys
Samantha Riggen and
Christopher Trembley have been named partners. Samantha represents clients in all areas of business and commercial matters with an emphasis on construction litigation on both public and private projects. Christopher’s practice also focuses on construction litigation on behalf of a wide spectrum of industry-stakeholder clients, including suppliers, contractors, and owners. Both work in our firm’s Westlake Village office.
We are also pleased to announce we’ve hired two new associates.
Sarah La Mendola and
Madison Wedderspoon. Sarah has developed an expertise in a wide range of real estate, business, and corporate matters. She received her JD from the University of Pavia, one of the top universities in Italy, in 2012 and her LLM from UCLA in 2015. You can find Sarah in our Westlake Village office. Madison recently graduated from the Boyd School of Law cum laude, is based in our Las Vegas office and works in the areas of business law, contracts, healthcare law, construction, real estate, and common interest community transactional and litigation work.
Read the full story...Reprinted courtesy of
Gibbs Giden